Notice Information
Notice Title
BP1054 - Design and Build of Community Pavilion and Young People's Centre
Notice Description
This is the shortlisting stage. Please ensure you read the procurement documentation especially PART ONE and provide the required information. Broxtowe Borough Council (the Council) is undertaking this procurement to find a Contractor to finalise the design and build a Community Pavilion and Young People's Centre at Hickings Road, Recreation Ground in Stapleford, Nottingham. NG9 8PJ. This project forms one of six core projects identified in the Stapleford Town Improvement Plan (TIP) and is funded by Towns Fund Deal. The scope of the building works will comprise of the demolition of the existing changing pavilion and the construction of a new community leisure pavilion together with associated external works including installation of MUGA and replacement of skate park with community garden. A new 11 a-side 3G football pitch is also planned on the site, and it is envisaged that this will be constructed concurrent to the building contract for the new pavilion, albeit the football pitch will be constructed by others. The successful contractor for the Pavilion will be expected to coordinate and work collaboratively with the 3G pitch contractor to ensure a safe working environment and coordination of site access and use. Planning permission for the new pavilion has been approved (Reference 23/00051/REG3 dated 7th July 2023) which can be found: www.planning.broxtowe.gov.uk/ApplicationDetail?RefVal=23/00051/REG3 The works are planned to be let utilising either a JCT D&B 2016 or NEC4 Option A form of Building Contract on a design and build basis. The Council invites the successful Contractor to take a novation of the Architect and Structural Engineer appointments. The successful Contractor may however propose alternatives in the tender (Stage 2) process. The Building Services Engineer will be retained by the Council. The Contractor will be required to work collaboratively with the Client's professional team and the Clients' partners to coordinate the detailed design. It is envisaged that the works will commence Spring 2024 and take approximately 12 months. The project is funded by the Towns Deal and must be completed prior to April 2025. The Council requires a competitive build price and would imagine maximum price of bids to be up to the value of PS6.5m, but with potential to be lower. NOTE: All Candidates should access the 'Messages' section of the e-procurement system on a regular basis to check for any clarifications issued on this project and/or any public exchange of information between interested parties, before final submission of their bid. It is the sole responsibility of Candidates to do so.
Lot Information
Lot 1
See II.1.4 . Short Description and Part 3 of the Selection Stage documents. Additional information: NOTE: All Candidates should access the 'Messages' section of the e-procurement system on a regular basis to check for any clarifications issued on this project and/or any public exchange of information between interested parties, before final submission of their bid. It is the sole responsibility of Candidates to do so.
Notice Details
Publication & Lifecycle
- Open Contracting ID
- ocds-h6vhtk-03f938
- Publication Source
- Find A Tender Service
- Latest Notice
- https://www.find-tender.service.gov.uk/Notice/025884-2023
- Current Stage
- Tender
- All Stages
- Tender
Procurement Classification
- Notice Type
- Tender Notice
- Procurement Type
- Standard
- Procurement Category
- Works
- Procurement Method
- Selective
- Procurement Method Details
- Restricted procedure
- Tender Suitability
- Not specified
- Awardee Scale
- Not specified
Common Procurement Vocabulary (CPV)
- CPV Divisions
45 - Construction work
-
- CPV Codes
45200000 - Works for complete or part construction and civil engineering work
45210000 - Building construction work
Notice Value(s)
- Tender Value
- £6,500,000 £1M-£10M
- Lots Value
- Not specified
- Awards Value
- Not specified
- Contracts Value
- Not specified
Notice Dates
- Publication Date
- 1 Sep 20232 years ago
- Submission Deadline
- 2 Oct 2023Expired
- Future Notice Date
- Not specified
- Award Date
- Not specified
- Contract Period
- Not specified - Not specified
- Recurrence
- Not specified
Notice Status
- Tender Status
- Active
- Lots Status
- Active
- Awards Status
- Not Specified
- Contracts Status
- Not Specified
Buyer & Supplier
Contracting Authority (Buyer)
- Main Buyer
- BROXTOWE BOROUGH COUNCIL
- Contact Name
- Not specified
- Contact Email
- procurement@broxtowe.gov.uk
- Contact Phone
- +44 1159177777
Buyer Location
- Locality
- NOTTINGHAM
- Postcode
- NG9 1AB
- Post Town
- Nottingham
- Country
- England
-
- Major Region (ITL 1)
- TLF East Midlands (England)
- Basic Region (ITL 2)
- TLF1 Derbyshire and Nottinghamshire
- Small Region (ITL 3)
- TLF16 South Nottinghamshire
- Delivery Location
- TLF1 Derbyshire and Nottinghamshire
-
- Local Authority
- Broxtowe
- Electoral Ward
- Beeston West
- Westminster Constituency
- Broxtowe
Further Information
Open Contracting Data Standard (OCDS)
View full OCDS Record for this contracting process
The Open Contracting Data Standard (OCDS) is a framework designed to increase transparency and access to public procurement data in the public sector. It is widely used by governments and organisations worldwide to report on procurement processes and contracts.
{
"tag": [
"compiled"
],
"id": "ocds-h6vhtk-03f938-2023-09-01T16:05:11+01:00",
"date": "2023-09-01T16:05:11+01:00",
"ocid": "ocds-h6vhtk-03f938",
"initiationType": "tender",
"tender": {
"id": "BP1054",
"legalBasis": {
"id": "32014L0024",
"scheme": "CELEX"
},
"title": "BP1054 - Design and Build of Community Pavilion and Young People's Centre",
"status": "active",
"classification": {
"scheme": "CPV",
"id": "45210000",
"description": "Building construction work"
},
"mainProcurementCategory": "works",
"description": "This is the shortlisting stage. Please ensure you read the procurement documentation especially PART ONE and provide the required information. Broxtowe Borough Council (the Council) is undertaking this procurement to find a Contractor to finalise the design and build a Community Pavilion and Young People's Centre at Hickings Road, Recreation Ground in Stapleford, Nottingham. NG9 8PJ. This project forms one of six core projects identified in the Stapleford Town Improvement Plan (TIP) and is funded by Towns Fund Deal. The scope of the building works will comprise of the demolition of the existing changing pavilion and the construction of a new community leisure pavilion together with associated external works including installation of MUGA and replacement of skate park with community garden. A new 11 a-side 3G football pitch is also planned on the site, and it is envisaged that this will be constructed concurrent to the building contract for the new pavilion, albeit the football pitch will be constructed by others. The successful contractor for the Pavilion will be expected to coordinate and work collaboratively with the 3G pitch contractor to ensure a safe working environment and coordination of site access and use. Planning permission for the new pavilion has been approved (Reference 23/00051/REG3 dated 7th July 2023) which can be found: www.planning.broxtowe.gov.uk/ApplicationDetail?RefVal=23/00051/REG3 The works are planned to be let utilising either a JCT D&B 2016 or NEC4 Option A form of Building Contract on a design and build basis. The Council invites the successful Contractor to take a novation of the Architect and Structural Engineer appointments. The successful Contractor may however propose alternatives in the tender (Stage 2) process. The Building Services Engineer will be retained by the Council. The Contractor will be required to work collaboratively with the Client's professional team and the Clients' partners to coordinate the detailed design. It is envisaged that the works will commence Spring 2024 and take approximately 12 months. The project is funded by the Towns Deal and must be completed prior to April 2025. The Council requires a competitive build price and would imagine maximum price of bids to be up to the value of PS6.5m, but with potential to be lower. NOTE: All Candidates should access the 'Messages' section of the e-procurement system on a regular basis to check for any clarifications issued on this project and/or any public exchange of information between interested parties, before final submission of their bid. It is the sole responsibility of Candidates to do so.",
"value": {
"amount": 6500000,
"currency": "GBP"
},
"lots": [
{
"id": "1",
"description": "See II.1.4 . Short Description and Part 3 of the Selection Stage documents. Additional information: NOTE: All Candidates should access the 'Messages' section of the e-procurement system on a regular basis to check for any clarifications issued on this project and/or any public exchange of information between interested parties, before final submission of their bid. It is the sole responsibility of Candidates to do so.",
"contractPeriod": {
"durationInDays": 360
},
"hasRenewal": false,
"submissionTerms": {
"variantPolicy": "notAllowed"
},
"hasOptions": false,
"status": "active"
}
],
"items": [
{
"id": "1",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45200000",
"description": "Works for complete or part construction and civil engineering work"
}
],
"deliveryAddresses": [
{
"region": "UKF1"
}
],
"deliveryLocation": {
"description": "Borough of Broxtowe"
},
"relatedLot": "1"
}
],
"submissionMethod": [
"electronicSubmission",
"written"
],
"submissionMethodDetails": "https://www.eastmidstenders.org/",
"documents": [
{
"id": "economic",
"documentType": "economicSelectionCriteria"
}
],
"procurementMethod": "selective",
"procurementMethodDetails": "Restricted procedure",
"coveredBy": [
"GPA"
],
"tenderPeriod": {
"endDate": "2023-10-02T10:00:00+01:00"
},
"secondStage": {
"invitationDate": "2023-10-27T00:00:00+01:00"
},
"submissionTerms": {
"languages": [
"en"
]
},
"hasRecurrence": false,
"reviewDetails": "The contracting authority will incorporate a minimum 10 calendar day standstill period following electronic notification (minimum of 15 calendar days for any other means of communication) to tenderers of the award decision. This period allows unsuccessful tenderers to seek further debriefing from the contracting authority before the contract is entered into. If an appeal regarding the award of a contract has not been successfully resolved the Public Contracts Regulations 2015 (Si 2015 No 102) provide for aggrieved parties who have been harmed or are at risk of harm by a breach of the rules to take action in the High Court (England, Wales and Northern Ireland). Any such action must be brought promptly (generally within 3 months). Where a contract has not been entered into the Court may order the setting aside of the award decision or order the authority to amend any document and may award damages. If the contract has been entered into the Court may only award damages. The purpose of the standstill period referred to above is to allow parties to apply to the Courts to set aside the award decision before the contract is entered into."
},
"parties": [
{
"id": "GB-FTS-72728",
"name": "Broxtowe Borough Council",
"identifier": {
"legalName": "Broxtowe Borough Council",
"noIdentifierRationale": "notOnAnyRegister"
},
"address": {
"streetAddress": "Beeston",
"locality": "NOTTINGHAM",
"region": "UKF16",
"postalCode": "NG91AB",
"countryName": "United Kingdom"
},
"contactPoint": {
"telephone": "+44 1159177777",
"email": "procurement@broxtowe.gov.uk",
"url": "https://www.eastmidstenders.org/"
},
"roles": [
"buyer"
],
"details": {
"url": "http://www.broxtowe.gov.uk",
"classifications": [
{
"scheme": "TED_CA_TYPE",
"id": "REGIONAL_AUTHORITY",
"description": "Regional or local authority"
},
{
"scheme": "COFOG",
"id": "01",
"description": "General public services"
}
]
}
},
{
"id": "GB-FTS-91615",
"name": "Broxtowe Borough Council",
"identifier": {
"legalName": "Broxtowe Borough Council"
},
"address": {
"streetAddress": "Council Offices, Beeston",
"locality": "Nottingham",
"postalCode": "NG10 5LS",
"countryName": "United Kingdom"
},
"roles": [
"reviewBody"
]
}
],
"buyer": {
"id": "GB-FTS-72728",
"name": "Broxtowe Borough Council"
},
"language": "en"
}