New Distribution Centre located at the Port of Cardiff

{
    "tag": [
        "compiled"
    ],
    "id": "ocds-h6vhtk-02f3ce-2021-12-09T09:20:38Z",
    "date": "2021-12-09T09:20:38Z",
    "ocid": "ocds-h6vhtk-02f3ce",
    "initiationType": "tender",
    "tender": {
        "id": "2021/S 000-027744",
        "legalBasis": {
            "id": "32014L0024",
            "scheme": "CELEX"
        },
        "title": "New Distribution Centre located at the Port of Cardiff",
        "status": "active",
        "classification": {
            "scheme": "CPV",
            "id": "45213000",
            "description": "Construction work for commercial buildings, warehouses and industrial buildings, buildings relating to transport"
        },
        "mainProcurementCategory": "works",
        "description": "Associated British Ports (ABP) intend to procure a Contractor to deliver the design and construction of a 11,000m2 distribution center comprising warehouse and office accommodation and associated external works (including but not limited to its associated civils, landscaping, car parking, service yard and van storage) on a site covering approximately 24 acres at the Port of Cardiff as further detailed within Appendix 1 of this PQQ document.",
        "value": {
            "amount": 25000000,
            "currency": "GBP"
        },
        "lots": [
            {
                "id": "1",
                "description": "Associated British Ports (ABP) intend to procure a Contractor to deliver the design and construction of a 11,000m2 distribution center comprising warehouse and office accommodation and associated external works (including but not limited to its associated civils, landscaping, car parking, service yard and van storage) on a site covering approximately 24 acres at the Port of Cardiff as further detailed within Appendix 1 of this PQQ document.The overall duration of the design & construction of the works, is to be 8 months. The start date is envisaged to be March 2022 which would result in completion of the whole of the works by October 2022. Whilst the start & completion dates may move based on this procurement process, the overall durations for the design & construction of the works will remain as 8 months. The Contract will include key dates and sectional completion dates including conditions to be met for these dates as the Contractor will have to accommodate work (to be clearly defined in the scope & contract data part one) by others not employed by ABP. ABP intend to engage with the successful bidder under the NEC 4 ECC Option A form of contract with amendments which will include provisions for delay damages.The successful Contractor is required to take on full responsibility for the design in its entirety including the design provided by the Client. The Contractor is to complete the design and construct the works.The total estimated contract value is circa PS25 million.",
                "value": {
                    "amount": 25000000,
                    "currency": "GBP"
                },
                "contractPeriod": {
                    "durationInDays": 240
                },
                "hasRenewal": false,
                "secondStage": {
                    "minimumCandidates": 6,
                    "maximumCandidates": 6
                },
                "submissionTerms": {
                    "variantPolicy": "notAllowed"
                },
                "hasOptions": false,
                "status": "active"
            }
        ],
        "items": [
            {
                "id": "1",
                "additionalClassifications": [
                    {
                        "scheme": "CPV",
                        "id": "45213000",
                        "description": "Construction work for commercial buildings, warehouses and industrial buildings, buildings relating to transport"
                    },
                    {
                        "scheme": "CPV",
                        "id": "45213220",
                        "description": "Construction work for warehouses"
                    },
                    {
                        "scheme": "CPV",
                        "id": "45213221",
                        "description": "Warehouse stores construction work"
                    },
                    {
                        "scheme": "CPV",
                        "id": "45213260",
                        "description": "Stores depot construction work"
                    },
                    {
                        "scheme": "CPV",
                        "id": "45213251",
                        "description": "Industrial units construction work"
                    },
                    {
                        "scheme": "CPV",
                        "id": "45213200",
                        "description": "Construction work for warehouses and industrial buildings"
                    },
                    {
                        "scheme": "CPV",
                        "id": "45213250",
                        "description": "Construction work for industrial buildings"
                    }
                ],
                "deliveryAddresses": [
                    {
                        "region": "UK"
                    }
                ],
                "relatedLot": "1"
            }
        ],
        "participationFees": [
            {
                "id": "1",
                "type": [
                    "document"
                ]
            }
        ],
        "submissionMethod": [
            "electronicSubmission",
            "written"
        ],
        "submissionMethodDetails": "https://in-tendhost.co.uk/abp/aspx/Home",
        "documents": [
            {
                "id": "economic",
                "documentType": "economicSelectionCriteria"
            },
            {
                "id": "technical",
                "documentType": "technicalSelectionCriteria"
            }
        ],
        "procurementMethod": "selective",
        "procurementMethodDetails": "Negotiated procedure with prior call for competition",
        "tenderPeriod": {
            "endDate": "2021-12-09T12:00:00Z"
        },
        "secondStage": {
            "invitationDate": "2021-12-20T00:00:00Z"
        },
        "submissionTerms": {
            "languages": [
                "en"
            ],
            "bidValidityPeriod": {
                "durationInDays": 90
            }
        },
        "hasRecurrence": false,
        "amendments": [
            {
                "id": "1",
                "unstructuredChanges": [
                    {
                        "oldValue": {
                            "text": "II.2.4) Description of the procurementAssociated British Ports (ABP) intend to procure a Contractor to deliver the designand construction of a 11,000m2 distribution center comprising warehouse and officeaccommodation and associated external works (including but not limited to itsassociated civils, landscaping, car parking, service yard and van storage) on a sitecovering approximately 24 acres at the Port of Cardiff as further detailed withinAppendix 1 of this PQQ document. The overall duration of the design and constructionof the works, is to be 8 months. The start date is envisaged to be March 2022 whichwould result in completion of the whole of the works by October 2022. Whilst thestart and completion dates may move based on this procurement process, the overalldurations for the design and construction of the works will remain as 8 months. TheContract will include key dates and sectional completion dates including conditionsto be met for these dates as the Contractor will have to accommodate work (to beclearly defined in the scope and contract data part one) by others not employed byABP. ABP intend to engage with the successful bidder under the NEC 4 ECC OptionA form of contract with amendments which will include provisions for delaydamages. The successful Contractor is required to take on full responsibility for thedesign in its entirety including the design provided by the Client. The Contractor isto complete the design and construct the works. The total estimated contract valueis circa PS25 million."
                        },
                        "newValue": {
                            "text": "II.2.4) Description of the procurementAssociated British Ports (ABP) intend to procure a Contractor to deliver the designand construction of a 11,000m2 distribution center comprising warehouse and officeaccommodation and associated external works (including but not limited to itsassociated civils, landscaping, car parking, service yard and van storage) on a sitecovering approximately 24 acres at the Port of Cardiff as further detailed withinAppendix 1 of the PQQ document. The estimated duration for the design and construction of the works is 10 months.The Contract will include key dates and sectional completion dates including conditionsto be met for these dates as the Contractor will have to accommodate work (to beclearly defined in the scope and contract data part one) by others not employed byABP. ABP intend to engage with the successful bidder under the NEC 4 ECC OptionA form of contract with amendments which will include provisions for delaydamages. The successful Contractor is required to take on full responsibility for thedesign in its entirety including the design provided by the Client. The Contractor isto complete the design and construct the works.Organisations wishing to participate must submit a completed PQQ document by the 14th January 2022."
                        },
                        "where": {
                            "section": "II.2.4",
                            "label": "Notice"
                        }
                    },
                    {
                        "oldValue": {
                            "date": "2021-12-09T12:00:00Z"
                        },
                        "newValue": {
                            "date": "2022-01-14T17:00:00Z"
                        },
                        "where": {
                            "section": "IV.2.2",
                            "label": "Notice"
                        }
                    },
                    {
                        "oldValue": {
                            "text": "III.1.6) Deposits and guarantees requiredPreviously blank - no entry made"
                        },
                        "newValue": {
                            "text": "III.1.6) Deposits and guarantees requiredThe utility may require a parent company/bank guarantee and/or performance bond (as appropriate) as a condition of any contract to be awarded"
                        },
                        "where": {
                            "section": "III.1.6",
                            "label": "Notice"
                        }
                    },
                    {
                        "oldValue": {
                            "text": "Place of performance NUTS CodesUK - United Kingdom"
                        },
                        "newValue": {
                            "text": "Place of performance NUTS CodesUK L22 Cardiff"
                        },
                        "where": {
                            "section": "II.2.3",
                            "label": "Notice"
                        }
                    },
                    {
                        "oldValue": {
                            "text": "III.1.8) Legal form to be taken by the group of economic operators to whom the contract is to be awardedPreviously blank - no entry"
                        },
                        "newValue": {
                            "text": "III.1.8) Legal form to be taken by the group of economic operators to whom the contract is to be awardedNo specific legal form is required at this stage. However, the utility reserves the right to require the successful contractor to take a specific legal form and/or assume joint and several liability if bidding on a consortium/subcontracting basis. This will be subject to discussion during the procurement process."
                        },
                        "where": {
                            "section": "III.1.8",
                            "label": "Notice"
                        }
                    },
                    {
                        "oldValue": {
                            "text": "VI.4.1) Review bodyOfficial Name:Associated British PortsPostal Address: 25 Bedford StreetTown:LondonPostal Code:WC2E 9ESCountry:United KingdomE-mailprocurement@abports.co.uk"
                        },
                        "newValue": {
                            "text": "VI.4.1) Review bodyOfficial Name:High Court of JusticePostal Address: Royal Courts of Justice, StrandTown:LondonPostal Code:WC2A 2LLCountry:United Kingdom"
                        },
                        "where": {
                            "section": "VI.4.1",
                            "label": "Notice"
                        }
                    },
                    {
                        "oldValue": {
                            "text": "VI.4.2) Body responsible for mediation procedureOfficial Name:Associated British PortsPostal Address:25 Bedford StreetTown:LondonPostal Code:WC2E 9ESCountryUnited KingdomE-mail:procurement@abports.co.uk"
                        },
                        "newValue": {
                            "text": "VI.4.2) Body responsible for mediation procedureBlank - no entry made"
                        },
                        "where": {
                            "section": "VI.4.2",
                            "label": "Notice"
                        }
                    },
                    {
                        "oldValue": {
                            "text": "II.2.7) Duration of the contract, framework agreement or dynamic purchasing systemDuration in months: 8"
                        },
                        "newValue": {
                            "text": "II.2.7) Duration of the contract, framework agreement or dynamic purchasing systemDuration in months: 10"
                        },
                        "where": {
                            "section": "II.2.7",
                            "label": "Notice"
                        }
                    }
                ]
            }
        ]
    },
    "parties": [
        {
            "id": "GB-FTS-33698",
            "name": "Associated British Ports",
            "identifier": {
                "legalName": "Associated British Ports"
            },
            "address": {
                "streetAddress": "25 Bedford Street, London, WC2E 9ES",
                "locality": "London",
                "region": "UK",
                "postalCode": "WC2E 9ES",
                "countryName": "United Kingdom"
            },
            "contactPoint": {
                "email": "procurement@abports.co.uk",
                "url": "https://in-tendhost.co.uk/abp/aspx/Home"
            },
            "roles": [
                "buyer"
            ],
            "details": {
                "url": "https://in-tendhost.co.uk/abp/aspx/Tenders/Current",
                "buyerProfile": "https://in-tendhost.co.uk/abp/aspx/Tenders/Current",
                "classifications": [
                    {
                        "scheme": "TED_CE_ACTIVITY",
                        "id": "PORT_RELATED_ACTIVITIES",
                        "description": "Port-related activities"
                    }
                ]
            }
        },
        {
            "id": "GB-FTS-6635",
            "name": "Associated British Ports",
            "identifier": {
                "legalName": "Associated British Ports"
            },
            "address": {
                "streetAddress": "25 Bedford Street",
                "locality": "London",
                "postalCode": "WC2E 9ES",
                "countryName": "United Kingdom"
            },
            "contactPoint": {
                "email": "procurement@abports.co.uk"
            },
            "roles": [
                "reviewBody",
                "mediationBody"
            ],
            "details": {
                "url": "https://in-tendhost.co.uk/abp/aspx/Home"
            }
        }
    ],
    "buyer": {
        "id": "GB-FTS-33698",
        "name": "Associated British Ports"
    },
    "language": "en"
}