Notice Information
Notice Title
Repair and Maintenance Services to Tenanted and Vacant properties and Communal Areas, Communal Plumbing and Tank Chlorination Services and Specialist Metalwork Services
Notice Description
The aim of this procurement is to appoint a single service provider to act as primary contractor for Lots 1 to 14 undertaking 60% of the works by value. There is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services for Lots 1-13. For Lot 15 only, a single service provider will act as secondary contractor to undertake 40% of the works by value. The Council does not guarantee or warrant the percentage of work given to any contractor. Repairs and maintenance works shall be carried out within defined priority timescale categories and Tenderer's shall be invited to tender an Adjustment Percentage to the Detailed Rates set out at Schedule 2 to the draft Contract contained within Volume 2, to act as primary Contractor.
Lot Information
The provision of Repair and Maintenance Services to Tenanted Properties: Eastern Area
The aim of this procurement is to appoint a single service provider to act as primary contractor for the Eastern area repairs tenanted contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/34D6MB4U8C
Options: The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each.
The provision of Repair and Maintenance Services to Tenanted Properties: Southern AreaThe aim of this procurement is to appoint a single service provider to act as primary contractor for the Southern area repairs tenanted contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/S7VYS634BB
Options: The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each.
The provision of Repair and Maintenance Services to Tenanted Properties: Central AreaThe aim of this procurement is to appoint a single service provider to act as primary contractor for the Central area repairs tenanted contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/T6YRZ7J85S
Options: The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each.
The provision of Repair and Maintenance Services to Tenanted Properties: Western AreaThe aim of this procurement is to appoint a single service provider to act as primary contractor for the Western area repairs tenanted contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/37M2ZTY588
Options: The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each.
The provision of Repair and Maintenance Services to Vacant Properties: Eastern AreaThe aim of this procurement is to appoint a single service provider to act as primary contractor for the Eastern area repairs Vacant properties contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/NRXPU7C2KR
Options: The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each.
The provision of Repair and Maintenance Services to Vacant Properties: Southern AreaThe aim of this procurement is to appoint a single service provider to act as primary contractor for the Southern area repairs vacant properties contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/G2BZZV88AE
Options: The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each.
The provision of Repair and Maintenance Services to Vacant Properties: Central AreaThe aim of this procurement is to appoint a single service provider to act as primary contractor for the Central area repairs vacant properties contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/A4F2G6P957
Options: The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each.
The provision of Repair and Maintenance Services to Vacant Properties: Western AreaThe aim of this procurement is to appoint a single service provider to act as primary contractor for the Western area repairs vacant properties contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/A4F2G6P957
Options: The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each.
The provision of Repair and Maintenance Services to Communal Areas: Eastern AreaThe aim of this procurement is to appoint a single service provider to act as primary contractor for the Eastern area repairs communal area contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/56EUP24M63
Options: The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each.
The provision of Repair and Maintenance Services to Communal Areas: Southern AreaThe aim of this procurement is to appoint a single service provider to act as primary contractor for the Communal areas, Southern area repairs contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/CWX2S28S2Z
Options: The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each.
The provision of Repair and Maintenance Services to Communal Areas: Central AreaThe aim of this procurement is to appoint a single service provider to act as primary contractor for the Central area repairs Communal Area contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/ F5DQKM8G5K
Options: The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each.
The provision of Repair and Maintenance Services to Communal Areas: Western AreaThe aim of this procurement is to appoint a single service provider to act as primary contractor for the Western area repairs to communal areas contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/ RRP7R6WR4M
Options: The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each.
Communal Plumbing and Tank Chlorination Works (Primary Contractor 60%), boroughwideThe aim of this procurement is to appoint a single service provider to act as primary contractor for the Communal Plumbing and Tank Chlorination Works (Primary Contractor 60%), boroughwide contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/8488E3EPPD
Options: The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each.
Specialist Metal Works (Primary Contractor 60%) boroughwideThe aim of this procurement is to appoint a single service provider to act as primary contractor for the Specialist Metal Works (Primary Contractor 60%) boroughwide contract (details in Volume 2 - specification) to undertake 60% of the works by value, there will also be a separate secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/ W9254Z65G8
Options: The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each.
Specialist Metal Works (Secondary Contractor 40%) boroughwideThe aim of this procurement is to appoint a single service provider to act as secondary contractor for the Specialist Metal Works (Secondary Contractor 40%) boroughwide contract (details in Volume 2 - specification) to undertake 40% of the works by value, there will also be a separate primary contractor undertaking the remaining 60% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/Q429V8UB6T
Options: The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each.
Notice Details
Publication & Lifecycle
- Open Contracting ID
- ocds-h6vhtk-032d51
- Publication Source
- Find A Tender Service
- Latest Notice
- https://www.find-tender.service.gov.uk/Notice/009908-2022
- Current Stage
- Award
- All Stages
- Award
Procurement Classification
- Notice Type
- Award Notice
- Procurement Type
- Standard
- Procurement Category
- Services
- Procurement Method
- Open
- Procurement Method Details
- Open procedure
- Tender Suitability
- Not specified
- Awardee Scale
- Large, SME
Common Procurement Vocabulary (CPV)
- CPV Divisions
50 - Repair and maintenance services
-
- CPV Codes
50000000 - Repair and maintenance services
50700000 - Repair and maintenance services of building installations
Notice Value(s)
- Tender Value
- Not specified
- Lots Value
- Not specified
- Awards Value
- Not specified
- Contracts Value
- £43,100,949 £10M-£100M
Notice Dates
- Publication Date
- 13 Apr 20223 years ago
- Submission Deadline
- Not specified
- Future Notice Date
- Not specified
- Award Date
- 11 Jul 20214 years ago
- Contract Period
- Not specified - Not specified
- Recurrence
- Not specified
Notice Status
- Tender Status
- Complete
- Lots Status
- Cancelled
- Awards Status
- Active
- Contracts Status
- Active
Buyer & Supplier
Contracting Authority (Buyer)
- Main Buyer
- LONDON BOROUGH OF WANDSWORTH
- Contact Name
- Valerie Kuijpers
- Contact Email
- valerie.kuijpers@richmondandwandsworth.gov.uk
- Contact Phone
- +44 2088716114
Buyer Location
- Locality
- LONDON
- Postcode
- SW18 2PU
- Post Town
- South West London
- Country
- England
-
- Major Region (ITL 1)
- TLI London
- Basic Region (ITL 2)
- TLI3 Inner London - West
- Small Region (ITL 3)
- TLI34 Wandsworth
- Delivery Location
- TLI34 Wandsworth
-
- Local Authority
- Wandsworth
- Electoral Ward
- Wandsworth Town
- Westminster Constituency
- Putney
Further Information
Notice URLs
Open Contracting Data Standard (OCDS)
View full OCDS Record for this contracting process
The Open Contracting Data Standard (OCDS) is a framework designed to increase transparency and access to public procurement data in the public sector. It is widely used by governments and organisations worldwide to report on procurement processes and contracts.
{
"tag": [
"compiled"
],
"id": "ocds-h6vhtk-032d51-2022-04-13T14:05:11+01:00",
"date": "2022-04-13T14:05:11+01:00",
"ocid": "ocds-h6vhtk-032d51",
"description": "To view this notice, please click here: https://www.delta-esourcing.com/delta/viewNotice.html?noticeId=683081817 GO Reference: GO-2022413-PRO-19963931",
"initiationType": "tender",
"tender": {
"id": "ocds-h6vhtk-032d51",
"legalBasis": {
"id": "32014L0024",
"scheme": "CELEX"
},
"title": "Repair and Maintenance Services to Tenanted and Vacant properties and Communal Areas, Communal Plumbing and Tank Chlorination Services and Specialist Metalwork Services",
"status": "complete",
"classification": {
"scheme": "CPV",
"id": "50700000",
"description": "Repair and maintenance services of building installations"
},
"mainProcurementCategory": "services",
"description": "The aim of this procurement is to appoint a single service provider to act as primary contractor for Lots 1 to 14 undertaking 60% of the works by value. There is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services for Lots 1-13. For Lot 15 only, a single service provider will act as secondary contractor to undertake 40% of the works by value. The Council does not guarantee or warrant the percentage of work given to any contractor. Repairs and maintenance works shall be carried out within defined priority timescale categories and Tenderer's shall be invited to tender an Adjustment Percentage to the Detailed Rates set out at Schedule 2 to the draft Contract contained within Volume 2, to act as primary Contractor.",
"lots": [
{
"id": "1",
"title": "The provision of Repair and Maintenance Services to Tenanted Properties: Eastern Area",
"description": "The aim of this procurement is to appoint a single service provider to act as primary contractor for the Eastern area repairs tenanted contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/34D6MB4U8C",
"awardCriteria": {
"criteria": [
{
"type": "price"
}
]
},
"hasOptions": true,
"options": {
"description": "The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each."
},
"status": "cancelled"
},
{
"id": "2",
"title": "The provision of Repair and Maintenance Services to Tenanted Properties: Southern Area",
"description": "The aim of this procurement is to appoint a single service provider to act as primary contractor for the Southern area repairs tenanted contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/S7VYS634BB",
"awardCriteria": {
"criteria": [
{
"type": "price"
}
]
},
"hasOptions": true,
"options": {
"description": "The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each."
},
"status": "cancelled"
},
{
"id": "3",
"title": "The provision of Repair and Maintenance Services to Tenanted Properties: Central Area",
"description": "The aim of this procurement is to appoint a single service provider to act as primary contractor for the Central area repairs tenanted contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/T6YRZ7J85S",
"awardCriteria": {
"criteria": [
{
"type": "price"
}
]
},
"hasOptions": true,
"options": {
"description": "The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each."
},
"status": "cancelled"
},
{
"id": "4",
"title": "The provision of Repair and Maintenance Services to Tenanted Properties: Western Area",
"description": "The aim of this procurement is to appoint a single service provider to act as primary contractor for the Western area repairs tenanted contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/37M2ZTY588",
"awardCriteria": {
"criteria": [
{
"type": "price"
}
]
},
"hasOptions": true,
"options": {
"description": "The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each."
},
"status": "cancelled"
},
{
"id": "5",
"title": "The provision of Repair and Maintenance Services to Vacant Properties: Eastern Area",
"description": "The aim of this procurement is to appoint a single service provider to act as primary contractor for the Eastern area repairs Vacant properties contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/NRXPU7C2KR",
"awardCriteria": {
"criteria": [
{
"type": "price"
}
]
},
"hasOptions": true,
"options": {
"description": "The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each."
},
"status": "cancelled"
},
{
"id": "6",
"title": "The provision of Repair and Maintenance Services to Vacant Properties: Southern Area",
"description": "The aim of this procurement is to appoint a single service provider to act as primary contractor for the Southern area repairs vacant properties contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/G2BZZV88AE",
"awardCriteria": {
"criteria": [
{
"type": "price"
}
]
},
"hasOptions": true,
"options": {
"description": "The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each."
},
"status": "cancelled"
},
{
"id": "7",
"title": "The provision of Repair and Maintenance Services to Vacant Properties: Central Area",
"description": "The aim of this procurement is to appoint a single service provider to act as primary contractor for the Central area repairs vacant properties contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/A4F2G6P957",
"awardCriteria": {
"criteria": [
{
"type": "price"
}
]
},
"hasOptions": true,
"options": {
"description": "The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each."
},
"status": "cancelled"
},
{
"id": "8",
"title": "The provision of Repair and Maintenance Services to Vacant Properties: Western Area",
"description": "The aim of this procurement is to appoint a single service provider to act as primary contractor for the Western area repairs vacant properties contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/A4F2G6P957",
"awardCriteria": {
"criteria": [
{
"type": "price"
}
]
},
"hasOptions": true,
"options": {
"description": "The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each."
},
"status": "cancelled"
},
{
"id": "9",
"title": "The provision of Repair and Maintenance Services to Communal Areas: Eastern Area",
"description": "The aim of this procurement is to appoint a single service provider to act as primary contractor for the Eastern area repairs communal area contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/56EUP24M63",
"awardCriteria": {
"criteria": [
{
"type": "price"
}
]
},
"hasOptions": true,
"options": {
"description": "The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each."
},
"status": "cancelled"
},
{
"id": "10",
"title": "The provision of Repair and Maintenance Services to Communal Areas: Southern Area",
"description": "The aim of this procurement is to appoint a single service provider to act as primary contractor for the Communal areas, Southern area repairs contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/CWX2S28S2Z",
"awardCriteria": {
"criteria": [
{
"type": "price"
}
]
},
"hasOptions": true,
"options": {
"description": "The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each."
},
"status": "cancelled"
},
{
"id": "11",
"title": "The provision of Repair and Maintenance Services to Communal Areas: Central Area",
"description": "The aim of this procurement is to appoint a single service provider to act as primary contractor for the Central area repairs Communal Area contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/ F5DQKM8G5K",
"awardCriteria": {
"criteria": [
{
"type": "price"
}
]
},
"hasOptions": true,
"options": {
"description": "The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each."
},
"status": "cancelled"
},
{
"id": "12",
"title": "The provision of Repair and Maintenance Services to Communal Areas: Western Area",
"description": "The aim of this procurement is to appoint a single service provider to act as primary contractor for the Western area repairs to communal areas contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/ RRP7R6WR4M",
"awardCriteria": {
"criteria": [
{
"type": "price"
}
]
},
"hasOptions": true,
"options": {
"description": "The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each."
},
"status": "cancelled"
},
{
"id": "13",
"title": "Communal Plumbing and Tank Chlorination Works (Primary Contractor 60%), boroughwide",
"description": "The aim of this procurement is to appoint a single service provider to act as primary contractor for the Communal Plumbing and Tank Chlorination Works (Primary Contractor 60%), boroughwide contract (details in Volume 2 - specification) to undertake 60% of the works by value, there is already an existing secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/8488E3EPPD",
"awardCriteria": {
"criteria": [
{
"type": "price"
}
]
},
"hasOptions": true,
"options": {
"description": "The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each."
},
"status": "cancelled"
},
{
"id": "14",
"title": "Specialist Metal Works (Primary Contractor 60%) boroughwide",
"description": "The aim of this procurement is to appoint a single service provider to act as primary contractor for the Specialist Metal Works (Primary Contractor 60%) boroughwide contract (details in Volume 2 - specification) to undertake 60% of the works by value, there will also be a separate secondary contractor undertaking the remaining 40% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/ W9254Z65G8",
"awardCriteria": {
"criteria": [
{
"type": "price"
}
]
},
"hasOptions": true,
"options": {
"description": "The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each."
},
"status": "cancelled"
},
{
"id": "15",
"title": "Specialist Metal Works (Secondary Contractor 40%) boroughwide",
"description": "The aim of this procurement is to appoint a single service provider to act as secondary contractor for the Specialist Metal Works (Secondary Contractor 40%) boroughwide contract (details in Volume 2 - specification) to undertake 40% of the works by value, there will also be a separate primary contractor undertaking the remaining 60% of the works for the provision of the services. Additional information: To respond to this opportunity please click here: https://www.delta-esourcing.com/respond/Q429V8UB6T",
"awardCriteria": {
"criteria": [
{
"type": "price"
}
]
},
"hasOptions": true,
"options": {
"description": "The term of the proposed contract is 3 years (36 months) to commence on 1.10.2021 with the option at the absolute discretion of the Council to extend for a further period or periods of up to four years (48 months) which will be awarded in two stages of 24 months each."
},
"status": "cancelled"
}
],
"items": [
{
"id": "1",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "50000000",
"description": "Repair and maintenance services"
}
],
"deliveryAddresses": [
{
"region": "UKI34"
}
],
"deliveryLocation": {
"description": "Wandsworth"
},
"relatedLot": "1"
},
{
"id": "2",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "50000000",
"description": "Repair and maintenance services"
}
],
"deliveryAddresses": [
{
"region": "UKI34"
}
],
"deliveryLocation": {
"description": "Wandsworth"
},
"relatedLot": "2"
},
{
"id": "3",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "50000000",
"description": "Repair and maintenance services"
}
],
"deliveryAddresses": [
{
"region": "UKI34"
}
],
"deliveryLocation": {
"description": "Wandsworth"
},
"relatedLot": "3"
},
{
"id": "4",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "50000000",
"description": "Repair and maintenance services"
}
],
"deliveryAddresses": [
{
"region": "UKI34"
}
],
"deliveryLocation": {
"description": "Wandsworth"
},
"relatedLot": "4"
},
{
"id": "5",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "50000000",
"description": "Repair and maintenance services"
}
],
"deliveryAddresses": [
{
"region": "UKI34"
}
],
"deliveryLocation": {
"description": "Wandsworth"
},
"relatedLot": "5"
},
{
"id": "6",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "50000000",
"description": "Repair and maintenance services"
}
],
"deliveryAddresses": [
{
"region": "UKI34"
}
],
"deliveryLocation": {
"description": "Wandsworth"
},
"relatedLot": "6"
},
{
"id": "7",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "50000000",
"description": "Repair and maintenance services"
}
],
"deliveryAddresses": [
{
"region": "UKI34"
}
],
"deliveryLocation": {
"description": "Wandsworth"
},
"relatedLot": "7"
},
{
"id": "8",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "50000000",
"description": "Repair and maintenance services"
}
],
"deliveryAddresses": [
{
"region": "UKI34"
}
],
"deliveryLocation": {
"description": "Wandsworth"
},
"relatedLot": "8"
},
{
"id": "9",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "50000000",
"description": "Repair and maintenance services"
}
],
"deliveryAddresses": [
{
"region": "UKI34"
}
],
"deliveryLocation": {
"description": "Wandsworth"
},
"relatedLot": "9"
},
{
"id": "10",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "50000000",
"description": "Repair and maintenance services"
}
],
"deliveryAddresses": [
{
"region": "UKI34"
}
],
"deliveryLocation": {
"description": "Wandsworth"
},
"relatedLot": "10"
},
{
"id": "11",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "50000000",
"description": "Repair and maintenance services"
}
],
"deliveryAddresses": [
{
"region": "UKI34"
}
],
"deliveryLocation": {
"description": "Wandsworth"
},
"relatedLot": "11"
},
{
"id": "12",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "50000000",
"description": "Repair and maintenance services"
}
],
"deliveryAddresses": [
{
"region": "UKI34"
}
],
"deliveryLocation": {
"description": "Wandsworth"
},
"relatedLot": "12"
},
{
"id": "13",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "50000000",
"description": "Repair and maintenance services"
}
],
"deliveryAddresses": [
{
"region": "UKI34"
}
],
"deliveryLocation": {
"description": "Wandsworth"
},
"relatedLot": "13"
},
{
"id": "14",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "50000000",
"description": "Repair and maintenance services"
}
],
"deliveryAddresses": [
{
"region": "UKI34"
}
],
"deliveryLocation": {
"description": "Wandsworth"
},
"relatedLot": "14"
},
{
"id": "15",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "50000000",
"description": "Repair and maintenance services"
}
],
"deliveryAddresses": [
{
"region": "UKI34"
}
],
"deliveryLocation": {
"description": "Wandsworth"
},
"relatedLot": "15"
}
],
"procurementMethod": "open",
"procurementMethodDetails": "Open procedure",
"reviewDetails": "The Council will incorporate a minimum 10 calendar day standstill period at the point where contract award is communicated to tenderers. Applicants who are unsuccessful shall be informed by the Council as soon as possible after the decision has been made as to the reasons why the applicant was unsuccessful. If an appeal regarding the award of the contract has not been successfully resolved, The Public Contracts Regulations 2015(SI 2015 No. 102) provide for aggrieved parties who have been harmed or are at risk of harm by breach of the rules to take legal action. Any such action must be brought within the applicable limitation period. Where a contract has not been entered into, the court may order the setting aside of the award decision or order the authorities to amend any document and may award damages. If the contract has been entered into the court may, depending on the circumstances, award damages, make a declaration of ineffectiveness, order the relevant authority to pay a fine, and/or order that the duration of the contract be shortened. The purpose of the standstill period referred to above is to allow the parties to apply to the courts to set aside the award decision before the contract is entered into."
},
"awards": [
{
"id": "009908-2022-CPT2536-1",
"relatedLots": [
"1"
],
"title": "The Provision of Repair and Maintenance Services to Tenanted Properties Eastern Area",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-49999",
"name": "Purdy Contracts Limited"
}
]
},
{
"id": "009908-2022-2",
"relatedLots": [
"2"
],
"title": "The Provision of Repair and Maintenance Services to Tenanted Properties - Southern Area",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-50000",
"name": "Breyer Group PLC"
}
]
},
{
"id": "009908-2022-2526-3",
"relatedLots": [
"3"
],
"title": "The Provision of Repair and Maintenance Services to Tenanted Properties - Cdentral Area",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-50001",
"name": "Breyer Group PLC"
}
]
},
{
"id": "009908-2022-2526L4-4",
"relatedLots": [
"4"
],
"title": "The Provision of Repair and Maintenance Services to Tenanted Properties - Western Area",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-50002",
"name": "Purdy contracts"
}
]
},
{
"id": "009908-2022-CPT2536L5-5",
"relatedLots": [
"5"
],
"title": "The Provision of Repair and Maintenance Services to Vacant Properties - Eastern Area",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-50003",
"name": "MNM Property Services Ltd"
}
]
},
{
"id": "009908-2022-2536L6-6",
"relatedLots": [
"6"
],
"title": "The Provision of Repair and Maintenance Services to Vacant Properties - Southern Area",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-50004",
"name": "Purdy Contracts Ltd"
}
]
},
{
"id": "009908-2022-2536L7-7",
"relatedLots": [
"7"
],
"title": "The Provision of Repair and Maintenance Services to Vacant Properties - Central Area",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-50005",
"name": "Purdy Contract Ltd"
}
]
},
{
"id": "009908-2022-2536L8-8",
"relatedLots": [
"8"
],
"title": "The Provision of Repair and Maintenance Services to Vacant Properties - Western",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-50003",
"name": "MNM Property Services Ltd"
}
]
},
{
"id": "009908-2022-2536L9-9",
"relatedLots": [
"9"
],
"title": "The Provision of Repair and Maintenance Services to Communal Areas - Eastern Areas",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-50006",
"name": "F G Keen Ltd"
}
]
},
{
"id": "009908-2022-2536L10-10",
"relatedLots": [
"10"
],
"title": "The Provision of Repair and Maintenance Services to Communal Areas - Southern",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-50007",
"name": "Breyer Group Plc"
}
]
},
{
"id": "009908-2022-2536L11-11",
"relatedLots": [
"11"
],
"title": "The Provision of Repair and Maintenance Services to Communal Areas - Central",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-50008",
"name": "F G Keen Ltd"
}
]
},
{
"id": "009908-2022-2536L12-12",
"relatedLots": [
"12"
],
"title": "The Provision of Repair and Maintenance Services to Communal Areas - Western",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-50007",
"name": "Breyer Group Plc"
}
]
},
{
"id": "009908-2022-2536L13-13",
"relatedLots": [
"13"
],
"title": "Communal Plumbing and Tank Chlorination Works",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-50009",
"name": "Drain Surgeon Services Ltd"
}
]
},
{
"id": "009908-2022-2536L14-14",
"relatedLots": [
"14"
],
"title": "Provision of Specialist Metal Works - Primary Contractor",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-50010",
"name": "John Carroll Sons Metal Works Ltd"
}
]
},
{
"id": "009908-2022-2536L15-15",
"relatedLots": [
"15"
],
"title": "Provision of Specialist Metal Works - Secondary Contractor",
"status": "active",
"suppliers": [
{
"id": "GB-FTS-50011",
"name": "W C Evans and Sons (Engs) Ltd"
}
]
}
],
"parties": [
{
"id": "GB-FTS-1497",
"name": "London Borough of Wandsworth",
"identifier": {
"legalName": "London Borough of Wandsworth"
},
"address": {
"streetAddress": "Town Hall, Wandsworth High Street",
"locality": "London",
"region": "UKI34",
"postalCode": "SW18 2PU",
"countryName": "United Kingdom"
},
"contactPoint": {
"name": "Valerie Kuijpers",
"telephone": "+44 2088716114",
"email": "valerie.kuijpers@richmondandwandsworth.gov.uk"
},
"roles": [
"buyer"
],
"details": {
"url": "https://www.delta-esourcing.com",
"buyerProfile": "https://www.wandsworth.gov.uk",
"classifications": [
{
"scheme": "TED_CA_TYPE",
"id": "REGIONAL_AUTHORITY",
"description": "Regional or local authority"
},
{
"scheme": "COFOG",
"id": "01",
"description": "General public services"
}
]
}
},
{
"id": "GB-FTS-49999",
"name": "Purdy Contracts Limited",
"identifier": {
"legalName": "Purdy Contracts Limited",
"id": "01830283"
},
"address": {
"streetAddress": "Brooklyn Lodge",
"locality": "London",
"region": "UKI4",
"postalCode": "E4 7RW",
"countryName": "United Kingdom"
},
"roles": [
"supplier"
],
"details": {
"scale": "sme"
}
},
{
"id": "GB-FTS-50000",
"name": "Breyer Group PLC",
"identifier": {
"legalName": "Breyer Group PLC",
"id": "00782931"
},
"address": {
"streetAddress": "Faringdon Avenue",
"locality": "Romford,",
"region": "UKH3",
"countryName": "United Kingdom"
},
"roles": [
"supplier"
],
"details": {
"scale": "large"
}
},
{
"id": "GB-FTS-50001",
"name": "Breyer Group PLC",
"identifier": {
"legalName": "Breyer Group PLC",
"id": "00782931"
},
"address": {
"streetAddress": "Faringdon Avenue",
"locality": "Romford",
"region": "UKH3",
"postalCode": "RM3 *ST",
"countryName": "United Kingdom"
},
"roles": [
"supplier"
],
"details": {
"scale": "large"
}
},
{
"id": "GB-FTS-50002",
"name": "Purdy contracts",
"identifier": {
"legalName": "Purdy contracts",
"id": "01830283"
},
"address": {
"streetAddress": "Brooklyn Lodge,",
"locality": "London",
"region": "UKI4",
"postalCode": "E4 7RW",
"countryName": "United Kingdom"
},
"roles": [
"supplier"
],
"details": {
"scale": "sme"
}
},
{
"id": "GB-FTS-50003",
"name": "MNM Property Services Ltd",
"identifier": {
"legalName": "MNM Property Services Ltd",
"id": "03117531"
},
"address": {
"streetAddress": "Unit 30, Cygnus Business Centre,, Dalmeyer Road",
"locality": "London",
"region": "UKI7",
"postalCode": "NW10 2XA",
"countryName": "United Kingdom"
},
"roles": [
"supplier"
],
"details": {
"scale": "sme"
}
},
{
"id": "GB-FTS-50004",
"name": "Purdy Contracts Ltd",
"identifier": {
"legalName": "Purdy Contracts Ltd",
"id": "01830283"
},
"address": {
"streetAddress": "Brooklyn Lodge,",
"locality": "London",
"region": "UKI4",
"postalCode": "E4 7RW",
"countryName": "United Kingdom"
},
"roles": [
"supplier"
],
"details": {
"scale": "sme"
}
},
{
"id": "GB-FTS-50005",
"name": "Purdy Contract Ltd",
"identifier": {
"legalName": "Purdy Contract Ltd",
"id": "01830283"
},
"address": {
"streetAddress": "Brooklyn Lodge,",
"locality": "London",
"region": "UKI4",
"postalCode": "E4 7RW",
"countryName": "United Kingdom"
},
"roles": [
"supplier"
],
"details": {
"scale": "sme"
}
},
{
"id": "GB-FTS-50006",
"name": "F G Keen Ltd",
"identifier": {
"legalName": "F G Keen Ltd",
"id": "01510435"
},
"address": {
"streetAddress": "Unit 70a Wimbledon Stadium Business Centre,",
"locality": "London",
"region": "UKI6",
"postalCode": "SW17 0BA",
"countryName": "United Kingdom"
},
"roles": [
"supplier"
],
"details": {
"scale": "sme"
}
},
{
"id": "GB-FTS-50007",
"name": "Breyer Group Plc",
"identifier": {
"legalName": "Breyer Group Plc",
"id": "00782931"
},
"address": {
"streetAddress": "Farrington Avenue",
"locality": "Romford",
"region": "UKH3",
"postalCode": "RM3 8ST",
"countryName": "United Kingdom"
},
"roles": [
"supplier"
],
"details": {
"scale": "large"
}
},
{
"id": "GB-FTS-50008",
"name": "F G Keen Ltd",
"identifier": {
"legalName": "F G Keen Ltd",
"id": "01510435"
},
"address": {
"streetAddress": "Unit 70, Wimbledon Stadium Business Centre",
"locality": "London",
"region": "UKI6",
"postalCode": "SW17 OBA",
"countryName": "United Kingdom"
},
"roles": [
"supplier"
],
"details": {
"scale": "large"
}
},
{
"id": "GB-FTS-50009",
"name": "Drain Surgeon Services Ltd",
"identifier": {
"legalName": "Drain Surgeon Services Ltd",
"id": "03710610"
},
"address": {
"streetAddress": "5 Bridge Parade, Waddon road",
"locality": "Croydon",
"region": "UKI62",
"postalCode": "CRO 4JH",
"countryName": "United Kingdom"
},
"roles": [
"supplier"
],
"details": {
"scale": "sme"
}
},
{
"id": "GB-FTS-50010",
"name": "John Carroll Sons Metal Works Ltd",
"identifier": {
"legalName": "John Carroll Sons Metal Works Ltd",
"id": "11472267"
},
"address": {
"streetAddress": "Unit 14 Liongate Enterprise Park, 80 Morden Road,",
"locality": "London",
"region": "UKI6",
"postalCode": "CR4 4NY",
"countryName": "United Kingdom"
},
"roles": [
"supplier"
],
"details": {
"scale": "sme"
}
},
{
"id": "GB-FTS-50011",
"name": "W C Evans and Sons (Engs) Ltd",
"identifier": {
"legalName": "W C Evans and Sons (Engs) Ltd",
"id": "1422809"
},
"address": {
"streetAddress": "2 Limes Avenue,, Penge",
"locality": "London",
"region": "UKI6",
"postalCode": "SE20 8QR",
"countryName": "United Kingdom"
},
"roles": [
"supplier"
],
"details": {
"scale": "sme"
}
},
{
"id": "GB-FTS-537",
"name": "Royal Courts of Justice",
"identifier": {
"legalName": "Royal Courts of Justice"
},
"address": {
"streetAddress": "The Strand",
"locality": "London",
"postalCode": "WC2A 2LL",
"countryName": "United Kingdom"
},
"contactPoint": {
"telephone": "+44 2079476000"
},
"roles": [
"reviewBody"
]
},
{
"id": "GB-FTS-50012",
"name": "Cabinet Office",
"identifier": {
"legalName": "Cabinet Office"
},
"address": {
"streetAddress": "Whitehall,, Westminster",
"locality": "London",
"postalCode": "SW1A 2AS",
"countryName": "United Kingdom"
},
"contactPoint": {
"telephone": "+44 2072761234"
},
"roles": [
"mediationBody"
]
},
{
"id": "GB-FTS-12928",
"name": "Cabinet Office",
"identifier": {
"legalName": "Cabinet Office"
},
"address": {
"streetAddress": "70 Whitehall,, Westminster",
"locality": "London",
"postalCode": "SW1A 2AS",
"countryName": "United Kingdom"
},
"contactPoint": {
"telephone": "+44 2072761234"
},
"roles": [
"reviewContactPoint"
]
}
],
"buyer": {
"id": "GB-FTS-1497",
"name": "London Borough of Wandsworth"
},
"contracts": [
{
"id": "009908-2022-CPT2536-1",
"awardID": "009908-2022-CPT2536-1",
"title": "The Provision of Repair and Maintenance Services to Tenanted Properties Eastern Area",
"status": "active",
"value": {
"amount": 5573750,
"currency": "GBP"
},
"dateSigned": "2021-07-12T00:00:00+01:00"
},
{
"id": "009908-2022-2",
"awardID": "009908-2022-2",
"title": "The Provision of Repair and Maintenance Services to Tenanted Properties - Southern Area",
"status": "active",
"value": {
"amount": 3643962,
"currency": "GBP"
},
"dateSigned": "2021-07-12T00:00:00+01:00"
},
{
"id": "009908-2022-2526-3",
"awardID": "009908-2022-2526-3",
"title": "The Provision of Repair and Maintenance Services to Tenanted Properties - Cdentral Area",
"status": "active",
"value": {
"amount": 3181500,
"currency": "GBP"
},
"dateSigned": "2021-07-12T00:00:00+01:00"
},
{
"id": "009908-2022-2526L4-4",
"awardID": "009908-2022-2526L4-4",
"title": "The Provision of Repair and Maintenance Services to Tenanted Properties - Western Area",
"status": "active",
"value": {
"amount": 3858750,
"currency": "GBP"
},
"dateSigned": "2021-07-12T00:00:00+01:00"
},
{
"id": "009908-2022-CPT2536L5-5",
"awardID": "009908-2022-CPT2536L5-5",
"title": "The Provision of Repair and Maintenance Services to Vacant Properties - Eastern Area",
"status": "active",
"value": {
"amount": 3175200,
"currency": "GBP"
},
"dateSigned": "2021-07-12T00:00:00+01:00"
},
{
"id": "009908-2022-2536L6-6",
"awardID": "009908-2022-2536L6-6",
"title": "The Provision of Repair and Maintenance Services to Vacant Properties - Southern Area",
"status": "active",
"value": {
"amount": 3123750,
"currency": "GBP"
},
"dateSigned": "2021-07-12T00:00:00+01:00"
},
{
"id": "009908-2022-2536L7-7",
"awardID": "009908-2022-2536L7-7",
"title": "The Provision of Repair and Maintenance Services to Vacant Properties - Central Area",
"status": "active",
"value": {
"amount": 2511250,
"currency": "GBP"
},
"dateSigned": "2021-07-12T00:00:00+01:00"
},
{
"id": "009908-2022-2536L8-8",
"awardID": "009908-2022-2536L8-8",
"title": "The Provision of Repair and Maintenance Services to Vacant Properties - Western",
"status": "active",
"value": {
"amount": 3270400,
"currency": "GBP"
},
"dateSigned": "2021-07-12T00:00:00+01:00"
},
{
"id": "009908-2022-2536L9-9",
"awardID": "009908-2022-2536L9-9",
"title": "The Provision of Repair and Maintenance Services to Communal Areas - Eastern Areas",
"status": "active",
"value": {
"amount": 2261000,
"currency": "GBP"
},
"dateSigned": "2021-07-12T00:00:00+01:00"
},
{
"id": "009908-2022-2536L10-10",
"awardID": "009908-2022-2536L10-10",
"title": "The Provision of Repair and Maintenance Services to Communal Areas - Southern",
"status": "active",
"value": {
"amount": 2272200,
"currency": "GBP"
},
"dateSigned": "2021-07-12T00:00:00+01:00"
},
{
"id": "009908-2022-2536L11-11",
"awardID": "009908-2022-2536L11-11",
"title": "The Provision of Repair and Maintenance Services to Communal Areas - Central",
"status": "active",
"value": {
"amount": 2793000,
"currency": "GBP"
},
"dateSigned": "2021-07-12T00:00:00+01:00"
},
{
"id": "009908-2022-2536L12-12",
"awardID": "009908-2022-2536L12-12",
"title": "The Provision of Repair and Maintenance Services to Communal Areas - Western",
"status": "active",
"value": {
"amount": 2349900,
"currency": "GBP"
},
"dateSigned": "2021-07-12T00:00:00+01:00"
},
{
"id": "009908-2022-2536L13-13",
"awardID": "009908-2022-2536L13-13",
"title": "Communal Plumbing and Tank Chlorination Works",
"status": "active",
"value": {
"amount": 3423700,
"currency": "GBP"
},
"dateSigned": "2021-07-12T00:00:00+01:00"
},
{
"id": "009908-2022-2536L14-14",
"awardID": "009908-2022-2536L14-14",
"title": "Provision of Specialist Metal Works - Primary Contractor",
"status": "active",
"value": {
"amount": 1008087.5,
"currency": "GBP"
},
"dateSigned": "2021-07-12T00:00:00+01:00"
},
{
"id": "009908-2022-2536L15-15",
"awardID": "009908-2022-2536L15-15",
"title": "Provision of Specialist Metal Works - Secondary Contractor",
"status": "active",
"value": {
"amount": 654500,
"currency": "GBP"
},
"dateSigned": "2021-07-12T00:00:00+01:00"
}
],
"bids": {
"statistics": [
{
"id": "1",
"measure": "bids",
"relatedLot": "1",
"value": 4
},
{
"id": "4",
"measure": "bids",
"relatedLot": "2",
"value": 4
},
{
"id": "7",
"measure": "bids",
"relatedLot": "3",
"value": 5
},
{
"id": "10",
"measure": "bids",
"relatedLot": "4",
"value": 5
},
{
"id": "13",
"measure": "bids",
"relatedLot": "5",
"value": 5
},
{
"id": "16",
"measure": "bids",
"relatedLot": "6",
"value": 5
},
{
"id": "19",
"measure": "bids",
"relatedLot": "7",
"value": 5
},
{
"id": "22",
"measure": "bids",
"relatedLot": "8",
"value": 5
},
{
"id": "25",
"measure": "bids",
"relatedLot": "9",
"value": 4
},
{
"id": "28",
"measure": "bids",
"relatedLot": "10",
"value": 4
},
{
"id": "31",
"measure": "bids",
"relatedLot": "11",
"value": 4
},
{
"id": "34",
"measure": "bids",
"relatedLot": "12",
"value": 4
},
{
"id": "37",
"measure": "bids",
"relatedLot": "13",
"value": 2
},
{
"id": "40",
"measure": "bids",
"relatedLot": "14",
"value": 2
},
{
"id": "43",
"measure": "bids",
"relatedLot": "15",
"value": 2
},
{
"id": "2",
"measure": "smeBids",
"relatedLot": "1",
"value": 4
},
{
"id": "5",
"measure": "smeBids",
"relatedLot": "2",
"value": 3
},
{
"id": "8",
"measure": "smeBids",
"relatedLot": "3",
"value": 4
},
{
"id": "11",
"measure": "smeBids",
"relatedLot": "4",
"value": 4
},
{
"id": "14",
"measure": "smeBids",
"relatedLot": "5",
"value": 4
},
{
"id": "17",
"measure": "smeBids",
"relatedLot": "6",
"value": 4
},
{
"id": "20",
"measure": "smeBids",
"relatedLot": "7",
"value": 4
},
{
"id": "23",
"measure": "smeBids",
"relatedLot": "8",
"value": 4
},
{
"id": "26",
"measure": "smeBids",
"relatedLot": "9",
"value": 3
},
{
"id": "29",
"measure": "smeBids",
"relatedLot": "10",
"value": 3
},
{
"id": "32",
"measure": "smeBids",
"relatedLot": "11",
"value": 3
},
{
"id": "35",
"measure": "smeBids",
"relatedLot": "12",
"value": 3
},
{
"id": "38",
"measure": "smeBids",
"relatedLot": "13",
"value": 2
},
{
"id": "41",
"measure": "smeBids",
"relatedLot": "14",
"value": 2
},
{
"id": "44",
"measure": "smeBids",
"relatedLot": "15",
"value": 2
},
{
"id": "3",
"measure": "electronicBids",
"relatedLot": "1",
"value": 4
},
{
"id": "6",
"measure": "electronicBids",
"relatedLot": "2",
"value": 4
},
{
"id": "9",
"measure": "electronicBids",
"relatedLot": "3",
"value": 5
},
{
"id": "12",
"measure": "electronicBids",
"relatedLot": "4",
"value": 5
},
{
"id": "15",
"measure": "electronicBids",
"relatedLot": "5",
"value": 5
},
{
"id": "18",
"measure": "electronicBids",
"relatedLot": "6",
"value": 5
},
{
"id": "21",
"measure": "electronicBids",
"relatedLot": "7",
"value": 5
},
{
"id": "24",
"measure": "electronicBids",
"relatedLot": "8",
"value": 5
},
{
"id": "27",
"measure": "electronicBids",
"relatedLot": "9",
"value": 4
},
{
"id": "30",
"measure": "electronicBids",
"relatedLot": "10",
"value": 4
},
{
"id": "33",
"measure": "electronicBids",
"relatedLot": "11",
"value": 4
},
{
"id": "36",
"measure": "electronicBids",
"relatedLot": "12",
"value": 4
},
{
"id": "39",
"measure": "electronicBids",
"relatedLot": "13",
"value": 2
},
{
"id": "42",
"measure": "electronicBids",
"relatedLot": "14",
"value": 2
},
{
"id": "45",
"measure": "electronicBids",
"relatedLot": "15",
"value": 2
}
]
},
"links": [
{
"rel": "prev",
"href": "https://ted.europa.eu/udl?uri=TED:NOTICE:541882-2020:TEXT:EN:HTML"
}
],
"language": "en"
}