Notice Information
Notice Title
Invitation to Tender (ITT) - Construction & Capital Works
Notice Description
The Framework will provide fully compliant, flexible and streamlined access to pre-qualified construction partners for the delivery of capital works projects across the education and wider public sectors throughout the UK. It will support a broad range of new-build construction and refurbishment schemes from schools, colleges and universities to healthcare and civic infrastructure using a variety of standard forms of contract (including JCT and NEC) to suit employer preference. The Framework is designed to reduce procurement burden at call-off, enable regional and project specific delivery through a lotting structure, and ensure alignment with the Procurement Act 2023, National Procurement Policy Statement (NPPS), the Construction Playbook and Gold Standard principles.
Lot Information
Lot 1 (a) - England (North) - JCT Minor Works Building Contract (MW)
Renewal: Maximum 3 extensions of 24 months per extension.
Lot 1 (b) - England (North) - JCT Intermediate Building Contract (IC)Renewal: Maximum 3 extensions of 24 months per extension.
Lot 1 (c)- England (North) - JCT Design and Build Contract (D&B)Renewal: Maximum 3 extensions of 24 months per extension.
Lot 1 (d) - England North - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)Renewal: Maximum 3 extensions of 24 months per extension.
Lot 1 (e) - England North - NEC 4 Engineering and Construction Short ContractRenewal: Maximum 3 extensions of 24 months per extension.
Lot 1 (f) - England North - NEC4 Engineering and Construction ContractRenewal: Maximum 3 extensions of 24 months per extension.
Lot 1 (g) - England North - NEC4 Engineering and Construction Contract with NEC4 Professional Services ContractRenewal: Maximum 3 extensions of 24 months per extension.
Lot 1 (h) - England North - NEC4 Engineering and Construction Contract with D&BRenewal: Maximum 3 extensions of 24 months per extension.
Lot 1 (i) - England North - National Federation of Demolition Contractors Direct Form of ContractRenewal: Maximum 3 extensions of 24 months per extension.
Lot 2 (a) - England Midlands - JCT Minor Works Building Contract (MW)Renewal: Maximum 3 extensions of 24 months per extension.
Lot 2 (b) - England Midlands- JCT Intermediate Building Contract (IC)Renewal: Maximum 3 extensions of 24 months per extension.
Lot 2 (c) - England Midlands- JCT Design and Build Contract (D&B)Renewal: Maximum 3 extensions of 24 months per extension.
Lot 2 (d) - England Midlands - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)Renewal: Maximum 3 extensions of 24 months per extension.
Lot 2 (e) - England Midlands - NEC 4 Engineering and Construction Short ContractRenewal: Maximum 3 extensions of 24 months per extension.
Lot 2 (f) - England Midlands - NEC4 Engineering and Construction ContractRenewal: Maximum 3 extensions of 24 months per extension.
Lot 2 (g) - England Midlands - NEC4 Engineering and Construction Contract with NEC4 Professional Services ContractRenewal: Maximum 3 extensions of 24 months per extension.
Lot 2 (h) - England Midlands - NEC4 Engineering and Construction Contract with D&BRenewal: Maximum 3 extensions of 24 months per extension.
Lot 2 (i) - England Midlands - National Federation of Demolition Contractors Direct Form of ContractRenewal: Maximum 3 extensions of 24 months per extension.
Lot 3 (a) - England South - JCT Minor Works Building Contract (MW)Renewal: Maximum 3 extensions of 24 months per extension.
Lot 3 (b) - England South - JCT Intermediate Building Contract (IC)Renewal: Maximum 3 extensions of 24 months per extension.
Lot 3 (c) - England South - JCT Design and Build Contract (D&B)Renewal: Maximum 3 extensions of 24 months per extension.
Lot 3 (d) - England South - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)Renewal: Maximum 3 extensions of 24 months per extension.
Lot 3 (e) - England South - NEC 4 Engineering and Construction Short ContractRenewal: Maximum 3 extensions of 24 months per extension.
Lot 3 (f) - England South - NEC4 Engineering and Construction ContractRenewal: Maximum 3 extensions of 24 months per extension.
Lot 3 (g) - England South - NEC4 Engineering and Construction Contract with NEC4 Professional Services ContractRenewal: Maximum 3 extensions of 24 months per extension.
Lot 3 (h) - England South - NEC4 Engineering and Construction Contract with D&BRenewal: Maximum 3 extensions of 24 months per extension.
Lot 3 (i) - England South - National Federation of Demolition Contractors Direct Form of ContractRenewal: Maximum 3 extensions of 24 months per extension.
Lot 4 (a) - Wales - JCT Minor Works Building Contract (MW)Renewal: Maximum 3 extensions of 24 months per extension.
Lot 4 (b) - Wales - JCT Intermediate Building Contract (IC)Renewal: Maximum 3 extensions of 24 months per extension.
Lot 4 (c) - Wales - JCT Design and Build Contract (D&B)Renewal: Maximum 3 extensions of 24 months per extension.
Lot 4 (d) - Wales - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)Renewal: Maximum 3 extensions of 24 months per extension.
Lot 4 (e) - Wales - NEC 4 Engineering and Construction Short ContractRenewal: Maximum 3 extensions of 24 months per extension.
Lot 4 (f) - Wales - NEC4 Engineering and Construction ContractRenewal: Maximum 3 extensions of 24 months per extension.
Lot 4 (g) - Wales - NEC4 Engineering and Construction Contract with NEC4 Professional Services ContractRenewal: Maximum 3 extensions of 24 months per extension.
Lot 4 (h) - Wales - NEC4 Engineering and Construction Contract with D&BRenewal: Maximum 3 extensions of 24 months per extension.
Lot 4 (i) - Wales - National Federation of Demolition Contractors Direct Form of ContractRenewal: Maximum 3 extensions of 24 months per extension.
Lot 5 (a) - Scotland - JCT Minor Works Building Contract (MW)Renewal: Maximum 3 extensions of 24 months per extension.
Lot 5 (b) - Scotland - JCT Intermediate Building Contract (IC)Renewal: Maximum 3 extensions of 24 months per extension.
Lot 5 (c) - Scotland - JCT Design and Build Contract (D&B)Renewal: Maximum 3 extensions of 24 months per extension.
Lot 5 (d) - Scotland - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)Renewal: Maximum 3 extensions of 24 months per extension.
Lot 5 (e) - Scotland - NEC 4 Engineering and Construction Short ContractRenewal: Maximum 3 extensions of 24 months per extension.
Lot 5 (f) - Scotland - NEC4 Engineering and Construction ContractRenewal: Maximum 3 extensions of 24 months per extension.
Lot 5 (g) - Scotland - NEC4 Engineering and Construction Contract with NEC4 Professional Services ContractRenewal: Maximum 3 extensions of 24 months per extension.
Lot 5 (h) - Scotland - NEC4 Engineering and Construction Contract with D&BRenewal: Maximum 3 extensions of 24 months per extension.
Lot 5 (i) - Scotland - National Federation of Demolition Contractors Direct Form of ContractRenewal: Maximum 3 extensions of 24 months per extension.
Planning Information
Engagement
Notice Details
Publication & Lifecycle
- Open Contracting ID
- ocds-h6vhtk-058142
- Publication Source
- Find A Tender Service
- Latest Notice
- https://www.find-tender.service.gov.uk/Notice/059699-2026
- Current Stage
- Award
- All Stages
- Planning, Tender, Award
Procurement Classification
- Notice Type
- UK6 - Contract Award Notice
- Procurement Type
- Standard
- Procurement Category
- Works
- Procurement Method
- Open
- Procurement Method Details
- Competitive flexible procedure
- Tender Suitability
- SME, VCSE
- Awardee Scale
- Large, SME
Common Procurement Vocabulary (CPV)
- CPV Divisions
-
- CPV Codes
45000000 - Construction work
Notice Value(s)
- Tender Value
- £9,500,000,000 £1B-£10B
- Lots Value
- £9,499,999,995 £1B-£10B
- Awards Value
- £211,111,110 £100M-£1B
- Contracts Value
- Not specified
Notice Dates
- Publication Date
- 25 Jun 2026Today
- Submission Deadline
- 30 Oct 2025Expired
- Future Notice Date
- 25 Sep 2025Expired
- Award Date
- 2 Jun 20263 weeks ago
- Contract Period
- 30 Jun 2026 - 30 Jun 2028 2-3 years
- Recurrence
- Not specified
Notice Status
- Tender Status
- Complete
- Lots Status
- Complete
- Awards Status
- Active
- Contracts Status
- Not Specified
Buyer & Supplier
Contracting Authority (Buyer)
- Main Buyer
- CRESCENT PURCHASING CONSORTIUM LIMITED
- Contact Name
- Available with D3 Tenders Premium →
- Contact Email
- Available with D3 Tenders Premium →
- Contact Phone
- Available with D3 Tenders Premium →
Buyer Location
- Locality
- SALFORD
- Postcode
- M6 6AJ
- Post Town
- Manchester
- Country
- England
-
- Major Region (ITL 1)
- TLD North West (England)
- Basic Region (ITL 2)
- TLD3 Greater Manchester
- Small Region (ITL 3)
- TLD34 Greater Manchester South West
- Delivery Location
- Not specified
-
- Local Authority
- Salford
- Electoral Ward
- Pendleton & Charlestown
- Westminster Constituency
- Salford
Further Information
Notice Documents
-
https://www.find-tender.service.gov.uk/Notice/059699-2026
25th June 2026 - Contract award notice on Find a Tender -
https://www.find-tender.service.gov.uk/Notice/058002-2026
19th June 2026 - Contract award notice on Find a Tender -
https://www.find-tender.service.gov.uk/Notice/055823-2026
12th June 2026 - Contract award notice on Find a Tender -
https://www.find-tender.service.gov.uk/Notice/062263-2025
3rd October 2025 - Tender notice on Find a Tender -
https://www.find-tender.service.gov.uk/Notice/046006-2025
5th August 2025 - Preliminary market engagement notice on Find a Tender
Notice URLs
Open Contracting Data Standard (OCDS)
The Open Contracting Data Standard (OCDS) is a framework designed to increase transparency and access to public procurement data in the public sector. It is widely used by governments and organisations worldwide to report on procurement processes and contracts.
{
"tag": [
"compiled"
],
"id": "ocds-h6vhtk-058142-2026-06-25T10:18:19+01:00",
"date": "2026-06-25T10:18:19+01:00",
"ocid": "ocds-h6vhtk-058142",
"initiationType": "tender",
"parties": [
{
"id": "GB-PPON-PZPR-8554-XHNX",
"name": "Crescent Purchasing Consortium Limited",
"identifier": {
"scheme": "GB-PPON",
"id": "PZPR-8554-XHNX"
},
"address": {
"streetAddress": "Procurement House, Leslie Hough Way",
"locality": "Salford",
"postalCode": "M6 6AJ",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKD34"
},
"contactPoint": {
"name": "Ria Logan",
"email": "r.logan@thecpc.ac.uk",
"telephone": "0161 974 0955"
},
"roles": [
"buyer"
],
"details": {
"classifications": [
{
"id": "publicUndertaking",
"scheme": "UK_CA_TYPE",
"description": "Public undertaking"
}
],
"url": "http://www.thecpc.ac.uk"
}
},
{
"id": "GB-PPON-PRRH-8298-MPBM",
"name": "Seddon Construction Limited",
"identifier": {
"scheme": "GB-PPON",
"id": "PRRH-8298-MPBM"
},
"address": {
"streetAddress": "Plodder Lane, Edge Fold",
"locality": "Bolton",
"postalCode": "BL4 0NN",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKD36"
},
"contactPoint": {
"name": "Bid Team",
"email": "tenders@seddon.co.uk",
"telephone": "01204 570400"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.seddon.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PTBH-4688-MMXN",
"name": "Walter Carefoot & Sons (Construction) Ltd.",
"identifier": {
"scheme": "GB-PPON",
"id": "PTBH-4688-MMXN"
},
"address": {
"streetAddress": "Blackpool Road, Longridge",
"locality": "Preston",
"postalCode": "PR3 3AL",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKD45"
},
"contactPoint": {
"name": "Steven Higham",
"email": "steven.higham@carefootplc.com",
"telephone": "01772783711"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.carefootplc.com",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PRLW-6359-JLDP",
"name": "EFT Construction Ltd",
"identifier": {
"scheme": "GB-PPON",
"id": "PRLW-6359-JLDP"
},
"address": {
"streetAddress": "Cobden House, 39A Cobden Road",
"locality": "Southport",
"postalCode": "PR9 7TR",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKD73"
},
"contactPoint": {
"name": "Sharon Stephenson",
"email": "tenders@eftconstruction.co.uk",
"telephone": "01704229431"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://eftgroup.co.uk/eft-construction/",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PVXV-4192-PRXH",
"name": "Senate Mech Ltd",
"identifier": {
"scheme": "GB-PPON",
"id": "PVXV-4192-PRXH"
},
"address": {
"streetAddress": "Senate Mech Ltd, , 13 Love Lane",
"locality": "Liverpool",
"postalCode": "L3 7DD",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKD72"
},
"contactPoint": {
"name": "Rhys Buxton",
"email": "tenders@senategroup.co.uk",
"telephone": "01512223411"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.senategroup.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PWDD-8548-WNWN",
"name": "Whitfield & Brown (Developments) Ltd",
"identifier": {
"scheme": "GB-PPON",
"id": "PWDD-8548-WNWN"
},
"address": {
"streetAddress": "Halton House, Gorsey Lane",
"locality": "Widnes",
"postalCode": "WA8 0RP",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKD71"
},
"contactPoint": {
"name": "Gemma Darroch",
"email": "bids@whitfieldbrown.com",
"telephone": "01514201000"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.whitfieldbrown.com",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PTLR-9847-LWTH",
"name": "Aptus Construction Ltd",
"identifier": {
"scheme": "GB-PPON",
"id": "PTLR-9847-LWTH"
},
"address": {
"streetAddress": "Unit 8 Cobblestone Court,, Hoults Yard",
"locality": "Newcastle-Upon-Tyne",
"postalCode": "NE6 1AB",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKC22"
},
"contactPoint": {
"name": "Luke Huntington",
"email": "tenders@aptusconstruction.co.uk",
"telephone": "07701290259"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.aptusconstruction.co.uk",
"scale": "sme",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PTBP-9736-DCWD",
"name": "GLC PROJECTS LTD",
"identifier": {
"scheme": "GB-PPON",
"id": "PTBP-9736-DCWD"
},
"address": {
"streetAddress": "The Manor House, West End",
"locality": "Sedgefield",
"postalCode": "TS21 2BW",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKC14"
},
"contactPoint": {
"name": "Graeme Cochrane",
"email": "info@glcprojects.co.uk",
"telephone": "07931269958"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.glcprojects.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PBPY-4769-XNBL",
"name": "Compass Developments (NE) Ltd",
"identifier": {
"scheme": "GB-PPON",
"id": "PBPY-4769-XNBL"
},
"address": {
"streetAddress": "Unit 9 Trafalgar Court, South Nelson Industrial Estate",
"locality": "Cramlington",
"postalCode": "NE23 1WF",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKC21"
},
"contactPoint": {
"name": "Ian Simpson",
"email": "ian.simpson@compassdev.co.uk",
"telephone": "01670737475"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.compassdev.co.uk",
"scale": "sme",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PHBV-8337-DNQL",
"name": "Brims Construction Ltd",
"identifier": {
"scheme": "GB-PPON",
"id": "PHBV-8337-DNQL"
},
"address": {
"streetAddress": "Ravensworth House, 5th Avenue Business Park",
"locality": "Gateshead",
"postalCode": "NE11 0HF",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKC22"
},
"roles": [
"tenderer"
],
"details": {
"url": "http://www.brimsconstruction.com",
"scale": "large",
"vcse": false
}
},
{
"id": "GB-PPON-PYRJ-3189-GLDM",
"name": "Rosslee Construction Ltd",
"identifier": {
"scheme": "GB-PPON",
"id": "PYRJ-3189-GLDM"
},
"address": {
"streetAddress": "30 Black Abbey Street",
"locality": "Accrington",
"postalCode": "BB5 1HT",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKD46"
},
"roles": [
"tenderer"
],
"details": {
"url": "http://www.rosslee.co.uk",
"scale": "sme",
"vcse": false
}
},
{
"id": "GB-PPON-PZRH-8617-DHJT",
"name": "FRANK ROGERS (BUILDING CONTRACTOR) LIMITED",
"identifier": {
"scheme": "GB-PPON",
"id": "PZRH-8617-DHJT"
},
"address": {
"streetAddress": "The Stables, Larkhill Lane",
"locality": "LIVERPOOL",
"postalCode": "L13 9BR",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKD72"
},
"contactPoint": {
"name": "Stephen Maddocks",
"email": "SMaddocks@frankrogers.co.uk",
"telephone": "0151 226 0323"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.frankrogers.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PRJV-5614-DHMZ",
"name": "Esh Construction Limited",
"identifier": {
"scheme": "GB-PPON",
"id": "PRJV-5614-DHMZ"
},
"address": {
"streetAddress": "Esh House, Bowburn North Ind Est",
"locality": "Durham",
"postalCode": "DH6 5PF",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKC14"
},
"contactPoint": {
"name": "Ethan Lunn",
"email": "ethan.lunn@esh.uk.com",
"telephone": "0191 377 4500"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.eshgroup.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PHWR-8769-WWGL",
"name": "Jupiter Construction LTD",
"identifier": {
"scheme": "GB-PPON",
"id": "PHWR-8769-WWGL"
},
"address": {
"streetAddress": "Unit 6a, Mortec Park",
"locality": "Leeds",
"postalCode": "LS15 4TA",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKE42"
},
"roles": [
"tenderer"
],
"details": {
"url": "https://jupiterconstruction.co.uk/",
"scale": "large",
"vcse": false
}
},
{
"id": "GB-PPON-PRGP-6331-RLDT",
"name": "Willliam Birch & Sons Ltd",
"identifier": {
"scheme": "GB-PPON",
"id": "PRGP-6331-RLDT"
},
"address": {
"streetAddress": "Link Road Court, Osbaldwick",
"locality": "York",
"postalCode": "YO10 3JQ",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKE21"
},
"roles": [
"tenderer"
],
"details": {
"url": "http://www.williambirch.co.uk",
"scale": "large",
"vcse": false
}
},
{
"id": "GB-PPON-PBRQ-1568-JRLT",
"name": "ASHFIELD PROJECTS (YORKSHIRE) LTD",
"identifier": {
"scheme": "GB-PPON",
"id": "PBRQ-1568-JRLT"
},
"address": {
"streetAddress": "Ashfield Projects (Yorkshire) Ltd, Sandown House",
"locality": "WETHERBY",
"postalCode": "LS22 7DN",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKE42"
},
"contactPoint": {
"name": "Pam Rayat",
"email": "prayat@ashfieldgroup.co.uk",
"telephone": "01133239656"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.ashfieldgroup.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PZGV-6617-DMBY",
"name": "7 FORMATION LIMITED",
"identifier": {
"scheme": "GB-PPON",
"id": "PZGV-6617-DMBY"
},
"address": {
"streetAddress": "23 Princewood Road",
"locality": "CORBY",
"postalCode": "NN17 4AP",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKF25"
},
"contactPoint": {
"name": "Kitty Ives",
"email": "preconstruction@7formation.co.uk",
"telephone": "+447786692501"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.7formation.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PZQD-1942-MTWY",
"name": "NRC Services Limited",
"identifier": {
"scheme": "GB-PPON",
"id": "PZQD-1942-MTWY"
},
"address": {
"streetAddress": "N R C House, Titterton Street",
"locality": "Sheffield",
"postalCode": "S9 3TE",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKE32"
},
"roles": [
"tenderer"
],
"details": {
"url": "http://www.nrcservices.co.uk",
"scale": "large",
"vcse": false
}
},
{
"id": "GB-PPON-PGTW-4456-TGCY",
"name": "GRAHAM",
"identifier": {
"scheme": "GB-PPON",
"id": "PGTW-4456-TGCY"
},
"address": {
"streetAddress": "5 BALLYGOWAN ROAD",
"locality": "Hillsborough",
"postalCode": "BT26 6HX",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKN0E"
},
"contactPoint": {
"name": "Sharon Truesdale",
"email": "sharon.truesdale@graham.co.uk",
"telephone": "028 9268 9500"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.graham.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited",
"identifier": {
"scheme": "GB-PPON",
"id": "PYQH-7266-GDPX"
},
"address": {
"streetAddress": "Blake House 3 , Frayswater Place",
"locality": "Uxbridge",
"postalCode": "UB8 2AD",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKI74"
},
"contactPoint": {
"name": "Elroi Bernardo",
"email": "Elroi.Bernardo@gallifordtry.co.uk",
"telephone": "07842 426313"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.gallifordtry.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PQZD-6932-BDNH",
"name": "MYC Group Ltd",
"identifier": {
"scheme": "GB-PPON",
"id": "PQZD-6932-BDNH"
},
"address": {
"streetAddress": "28 St. Albans Lane",
"locality": "LONDON",
"postalCode": "NW11 7QE",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKI71"
},
"contactPoint": {
"name": "Boaz Torfstein",
"email": "boaz@mycgroup.co.uk",
"telephone": "02080663244"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.mycgroup.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PJVM-7393-WBVP",
"name": "GALLAWAY CONSTRUCTION LIMITED",
"identifier": {
"scheme": "GB-PPON",
"id": "PJVM-7393-WBVP"
},
"address": {
"streetAddress": "The Old School House, Manchester Road",
"locality": "Manchester",
"postalCode": "M31 4UG",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKD34"
},
"contactPoint": {
"name": "Sam Eccleston",
"email": "sam.eccleston@gallaway.co.uk",
"telephone": "07754852623"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.gallaway.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PJZD-8216-PHJX",
"name": "AREA",
"identifier": {
"scheme": "GB-PPON",
"id": "PJZD-8216-PHJX"
},
"address": {
"streetAddress": "Bridge House, 4 Borough High Street",
"locality": "Southwark",
"postalCode": "SE1 9QQ",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKI44"
},
"contactPoint": {
"name": "Brian Poole",
"email": "BrianPoole@area.co.uk",
"telephone": "07702667323"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.area.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PYBB-4931-GPPD",
"name": "CBES",
"identifier": {
"scheme": "GB-PPON",
"id": "PYBB-4931-GPPD"
},
"address": {
"streetAddress": "Caledonia House, Lawmoor Street",
"locality": "Glasgow",
"postalCode": "G5 0US",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKM82"
},
"contactPoint": {
"name": "John Currie",
"email": "cbes.sales@city-holdings.co.uk",
"telephone": "07525 278 476"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.cbes.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PWNL-8777-NNQX",
"name": "John Turner Construction Group Ltd",
"identifier": {
"scheme": "GB-PPON",
"id": "PWNL-8777-NNQX"
},
"address": {
"streetAddress": "2 Preston Road, Grimsargh",
"locality": "Preston",
"postalCode": "PR2 5SD",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKD45"
},
"roles": [
"tenderer"
],
"details": {
"url": "http://www.johnturner.co.uk",
"scale": "large",
"vcse": false
}
},
{
"id": "GB-PPON-PLDN-9791-PJGH",
"name": "MBC Building Contractors",
"identifier": {
"scheme": "GB-PPON",
"id": "PLDN-9791-PJGH"
},
"address": {
"streetAddress": "Lyceum Works, George Street",
"locality": "Chadderton",
"postalCode": "OL9 9HY",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKD37"
},
"contactPoint": {
"name": "Sam Brierley",
"email": "sam@mbcbuilding.co.uk",
"telephone": "01616283333"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.mbcbuilding.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PDLR-6293-DLGH",
"name": "GMI CONSTRUCTION GROUP PLC",
"identifier": {
"scheme": "GB-PPON",
"id": "PDLR-6293-DLGH"
},
"address": {
"streetAddress": "Middleton House, Westland Road",
"locality": "LEEDS",
"postalCode": "LS11 5UH",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKE42"
},
"contactPoint": {
"name": "Kirsty Bridgwood",
"email": "kirsty.bridgwood@gmi.co.uk",
"telephone": "01132760505"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "https://gmi.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PBPZ-4782-JBVH",
"name": "Premier Modular Ltd",
"identifier": {
"scheme": "GB-PPON",
"id": "PBPZ-4782-JBVH"
},
"address": {
"streetAddress": "Catfoss Lane",
"locality": "Brandesburton",
"postalCode": "YO25 8EJ",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKE12"
},
"contactPoint": {
"name": "David Mills",
"email": "contact@premiermodular.co.uk",
"telephone": "01964545000"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.premiermodular.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PXDY-7891-BHYG",
"name": "RHODAR INDUSTRIAL SERVICES LIMITED",
"identifier": {
"scheme": "GB-PPON",
"id": "PXDY-7891-BHYG"
},
"address": {
"streetAddress": "Unit C, Astra Park, Parkside Lane",
"locality": "LEEDS",
"postalCode": "LS11 5SZ",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKE42"
},
"contactPoint": {
"name": "Darren Payne",
"email": "pqq@rhodar.co.uk",
"telephone": "0113 2700775"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.rhodar.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PHJX-3544-MTVP",
"name": "A.BUCKLER HAULAGE LIMITED",
"identifier": {
"scheme": "GB-PPON",
"id": "PHJX-3544-MTVP"
},
"address": {
"streetAddress": "24-28 Marsh Road",
"locality": "Middlesbrough",
"postalCode": "TS1 5LB",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKC12"
},
"contactPoint": {
"name": "Richard Love",
"email": "richard@abucklerdemolition.co.uk",
"telephone": "+447876205685"
},
"roles": [
"supplier",
"tenderer"
],
"details": {
"url": "http://www.abucklerdemolition.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PDNC-5796-MJWT",
"name": "DSM (DSM DEMOLITION LIMITED)",
"identifier": {
"scheme": "GB-PPON",
"id": "PDNC-5796-MJWT"
},
"address": {
"streetAddress": "Arden House Arden Road",
"locality": "BIRMINGHAM",
"postalCode": "B8 1DE",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKG31"
},
"contactPoint": {
"name": "Mr/Mrs Bid Manager",
"email": "tenders@dsmgroup.info",
"telephone": "01213222225"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.dsmgroup.info",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PDJQ-6122-BMVY",
"name": "PLANET INTERIOR PROJECTS LIMITED",
"identifier": {
"scheme": "GB-PPON",
"id": "PDJQ-6122-BMVY"
},
"address": {
"streetAddress": "Empress Business Park, 380 Chester Road",
"locality": "MANCHESTER",
"postalCode": "M16 9EA",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKD34"
},
"contactPoint": {
"name": "jeff noon",
"email": "jeff@planet-interiors.com",
"telephone": "07706351631"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.planet-interiors.com",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PTHJ-9659-VXHZ",
"name": "BSN Group Construction Ltd",
"identifier": {
"scheme": "GB-PPON",
"id": "PTHJ-9659-VXHZ"
},
"address": {
"streetAddress": "Dudley Court South,, West ,, Waterfront East, Level Street",
"locality": "Brierley Hill",
"postalCode": "DY5 1TD",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKG36"
},
"contactPoint": {
"name": "Sharnie Ellison",
"email": "proposals@bsn-group.co.uk",
"telephone": "01384376910"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.bsn-group.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PBXL-9667-CZWP",
"name": "VINCI Facilities",
"identifier": {
"scheme": "GB-PPON",
"id": "PBXL-9667-CZWP"
},
"address": {
"streetAddress": "Stuart House, Manor Way",
"locality": "Rainham",
"postalCode": "RM13 8RH",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKI52"
},
"contactPoint": {
"name": "Richard Odling",
"email": "buildingsolutions@vincifacilities.com",
"telephone": "03444 434650"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.vinci-facilities.com",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PPQD-9154-VBML",
"name": "A.R. CARTWRIGHT (CONSTRUCTION) LIMITED",
"identifier": {
"scheme": "GB-PPON",
"id": "PPQD-9154-VBML"
},
"address": {
"streetAddress": "Vicarage Street",
"locality": "NUNEATON",
"postalCode": "CV11 4AZ",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKG13"
},
"roles": [
"tenderer"
],
"details": {
"url": "http://www.cartwrighthomes.co.uk",
"scale": "large",
"vcse": false
}
},
{
"id": "GB-PPON-PMMH-8591-VGTY",
"name": "M & J Group (Construction & Roofing) Ltd.",
"identifier": {
"scheme": "GB-PPON",
"id": "PMMH-8591-VGTY"
},
"address": {
"streetAddress": "Hammond Road, Elms Ind Estate",
"locality": "Bedford",
"postalCode": "MK41 0UD",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKH24"
},
"contactPoint": {
"name": "Abigail Mormone",
"email": "portals@mjconstructiongroup.co.uk",
"telephone": "08448003912"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.mjconstructiongroup.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PJNB-7236-ZVCQ",
"name": "M & O BUILDING CONTRACTORS LIMITED",
"identifier": {
"scheme": "GB-PPON",
"id": "PJNB-7236-ZVCQ"
},
"address": {
"streetAddress": "York House, Leicester Road",
"locality": "LEICESTER",
"postalCode": "LE17 4HF",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKF22"
},
"contactPoint": {
"name": "Chloe Dyson",
"email": "justin@mobuilders.co.uk",
"telephone": "01455284390"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.mobuilders.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PTRJ-1317-LMRY",
"name": "Etec Group",
"identifier": {
"scheme": "GB-PPON",
"id": "PTRJ-1317-LMRY"
},
"address": {
"streetAddress": "98 High Road, 98/106 High Road",
"locality": "South Woodford",
"postalCode": "E182QH",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKI53"
},
"contactPoint": {
"name": "Jack Tresidder",
"email": "jtresidder@etec.group",
"telephone": "07535381533"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.etec.group",
"scale": "sme",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PTXD-1133-HVRW",
"name": "Maylarch Environmental Ltd",
"identifier": {
"scheme": "GB-PPON",
"id": "PTXD-1133-HVRW"
},
"address": {
"streetAddress": "Stable Courtyard, Worton Park",
"locality": "Witney",
"postalCode": "OX29 4SU",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKJ14"
},
"contactPoint": {
"name": "Kevin Bowerman",
"email": "enquiries@maylarch.co.uk",
"telephone": "01865 883 829"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.maylarch.co.uk",
"scale": "sme",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PDVH-1753-WZJH",
"name": "Mulalley and Company Ltd",
"identifier": {
"scheme": "GB-PPON",
"id": "PDVH-1753-WZJH"
},
"address": {
"streetAddress": "Teresa Gavin House , Woodford Avenue",
"locality": "Woodford",
"postalCode": "IG8 8FA",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKI53"
},
"contactPoint": {
"name": "Thomas Rowe",
"email": "procurement@mulalley.co.uk",
"telephone": "02085519999"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.mulalley.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PJPB-5212-BNDP",
"name": "Beard Construction",
"identifier": {
"scheme": "GB-PPON",
"id": "PJPB-5212-BNDP"
},
"address": {
"streetAddress": "Faraday Road, Dorcan",
"locality": "Swindon",
"postalCode": "SN3 5JY",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKK14"
},
"contactPoint": {
"name": "Mandi Cassar",
"email": "mandi.cassar@beardconstruction.co.uk",
"telephone": "07990019606"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.beardconstruction.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PBJZ-9979-PBMW",
"name": "Beardwell Construction Ltd",
"identifier": {
"scheme": "GB-PPON",
"id": "PBJZ-9979-PBMW"
},
"address": {
"streetAddress": "Beacon House, Threshelfords Business Park,, Inworth Road",
"locality": "Colchester",
"postalCode": "CO5 9SE",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKH34"
},
"contactPoint": {
"name": "Duncan Clark",
"email": "alerts@beardwell.com",
"telephone": "01376790079"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.beardwell.com",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PCMN-5796-PHGT",
"name": "Every Project Counts Ltd",
"identifier": {
"scheme": "GB-PPON",
"id": "PCMN-5796-PHGT"
},
"address": {
"streetAddress": "Unit 7, Kendal Court",
"locality": "Wickford",
"postalCode": "SS11 8YB",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKH37"
},
"contactPoint": {
"name": "Claire Mayell",
"email": "claire@everyprojectcounts.co.uk",
"telephone": "01277 652007"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.everyprojectcounts.co.uk",
"scale": "sme",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PGXX-7212-MLBQ",
"name": "Carmelcrest Limited",
"identifier": {
"scheme": "GB-PPON",
"id": "PGXX-7212-MLBQ"
},
"address": {
"streetAddress": "Suite 18, Block H, Peek Business Centre, Dunmow Road",
"locality": "Bishop's Stortford",
"postalCode": "CM23 5RG",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKH23"
},
"contactPoint": {
"name": "Matthew Chessum",
"email": "bidmanager@carmelcrest.co.uk",
"telephone": "01992718231"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.carmelcrest.co.uk",
"scale": "sme",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PLBB-6351-LDWL",
"name": "Standage & Co. Limited",
"identifier": {
"scheme": "GB-PPON",
"id": "PLBB-6351-LDWL"
},
"address": {
"streetAddress": "Unit 8, Glengall Business Centre",
"locality": "London",
"postalCode": "SE15 6NH",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKI44"
},
"roles": [
"tenderer"
],
"details": {
"url": "http://www.standage.co.uk",
"scale": "large",
"vcse": false
}
},
{
"id": "GB-PPON-PPTX-1438-QCTR",
"name": "TOTAL PROTECTION (CONTRACTING SERVICES) LTD",
"identifier": {
"scheme": "GB-PPON",
"id": "PPTX-1438-QCTR"
},
"address": {
"streetAddress": "Monometer House, Rectory Grove",
"locality": "LEIGH-ON-SEA",
"postalCode": "SS9 2HN",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKH31"
},
"roles": [
"tenderer"
],
"details": {
"url": "https://thetpgroup.co.uk/",
"scale": "large",
"vcse": false
}
},
{
"id": "GB-PPON-PTZX-3371-DHCD",
"name": "Knightsbridge Property Services Ltd",
"identifier": {
"scheme": "GB-PPON",
"id": "PTZX-3371-DHCD"
},
"address": {
"streetAddress": "Airport House, Purley Way",
"locality": "Croydon",
"postalCode": "CR0 0XZ",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKI62"
},
"contactPoint": {
"name": "Will McLaughlin",
"email": "Will.McLaughlin@kpsltd.co.uk",
"telephone": "0208 288 8503"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.kpsltd.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PBTV-4868-CNJH",
"name": "C.G. FRY AND SON LIMITED",
"identifier": {
"scheme": "GB-PPON",
"id": "PBTV-4868-CNJH"
},
"address": {
"streetAddress": "Litton Cheney,",
"locality": "DORCHESTER",
"postalCode": "DT2 9AS",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKK25"
},
"roles": [
"tenderer"
],
"details": {
"url": "http://www.cgfry.co.uk",
"scale": "large",
"vcse": false
}
},
{
"id": "GB-PPON-PHTT-9248-ZXMG",
"name": "CITYAXIS LIMITED",
"identifier": {
"scheme": "GB-PPON",
"id": "PHTT-9248-ZXMG"
},
"address": {
"streetAddress": "1St Floor, 346 Kensington High Street, Kensington, 346 Kensington High Street",
"locality": "LONDON",
"postalCode": "W14 8NS",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKI33"
},
"contactPoint": {
"name": "MARIE-ANGE BARLOW",
"email": "BIDS@CITYAXIS.CO.UK",
"telephone": "020 7368 6868"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.cityaxis.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PBPD-9992-MNVW",
"name": "D R W LTD.",
"identifier": {
"scheme": "GB-PPON",
"id": "PBPD-9992-MNVW"
},
"address": {
"streetAddress": "Unit 2 , 1 Annan Business Park",
"locality": "ANNAN",
"postalCode": "DG12 6TZ",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKM92"
},
"contactPoint": {
"name": "Christian White",
"email": "christian@drw-ltd.co.uk",
"telephone": "07999403430"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.drw-ltd.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
},
{
"id": "GB-PPON-PWGZ-4584-LXJJ",
"name": "CCG (SCOTLAND) LIMITED",
"identifier": {
"scheme": "GB-PPON",
"id": "PWGZ-4584-LXJJ"
},
"address": {
"streetAddress": "1 Cambuslang Road, Cambuslang Investment Park",
"locality": "GLASGOW",
"postalCode": "G32 8NB",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKM82"
},
"contactPoint": {
"name": "Darren McCann",
"email": "dmccann@c-c-g.co.uk",
"telephone": "0141 643 3733"
},
"roles": [
"tenderer",
"supplier"
],
"details": {
"url": "http://www.c-c-g.co.uk",
"scale": "large",
"vcse": false,
"publicServiceMissionOrganization": false,
"shelteredWorkshop": false
}
}
],
"buyer": {
"id": "GB-PPON-PZPR-8554-XHNX",
"name": "Crescent Purchasing Consortium Limited"
},
"planning": {
"milestones": [
{
"id": "engagement",
"type": "engagement",
"description": "Engagement",
"dueDate": "2025-08-30T23:59:59+01:00",
"status": "scheduled"
}
],
"documents": [
{
"id": "046006-2025",
"documentType": "marketEngagementNotice",
"noticeType": "UK2",
"description": "Preliminary market engagement notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/046006-2025",
"datePublished": "2025-08-05T10:39:01+01:00",
"format": "text/html"
}
]
},
"tender": {
"id": "CA16292",
"legalBasis": {
"id": "2023/54",
"scheme": "UKPGA",
"uri": "https://www.legislation.gov.uk/ukpga/2023/54/contents"
},
"title": "Invitation to Tender (ITT) - Construction & Capital Works",
"description": "The Framework will provide fully compliant, flexible and streamlined access to pre-qualified construction partners for the delivery of capital works projects across the education and wider public sectors throughout the UK. It will support a broad range of new-build construction and refurbishment schemes from schools, colleges and universities to healthcare and civic infrastructure using a variety of standard forms of contract (including JCT and NEC) to suit employer preference. The Framework is designed to reduce procurement burden at call-off, enable regional and project specific delivery through a lotting structure, and ensure alignment with the Procurement Act 2023, National Procurement Policy Statement (NPPS), the Construction Playbook and Gold Standard principles.",
"items": [
{
"id": "1",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "1"
},
{
"id": "2",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "2"
},
{
"id": "3",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "3"
},
{
"id": "4",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "4"
},
{
"id": "5",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "5"
},
{
"id": "6",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "6"
},
{
"id": "7",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "7"
},
{
"id": "8",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "8"
},
{
"id": "9",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "9"
},
{
"id": "10",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "10"
},
{
"id": "11",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "11"
},
{
"id": "12",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "12"
},
{
"id": "13",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "13"
},
{
"id": "14",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "14"
},
{
"id": "15",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "15"
},
{
"id": "16",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "16"
},
{
"id": "17",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "17"
},
{
"id": "18",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "18"
},
{
"id": "19",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "19"
},
{
"id": "20",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "20"
},
{
"id": "21",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "21"
},
{
"id": "22",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "22"
},
{
"id": "23",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "23"
},
{
"id": "24",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "24"
},
{
"id": "25",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "25"
},
{
"id": "26",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "26"
},
{
"id": "27",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "27"
},
{
"id": "28",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "28"
},
{
"id": "29",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "29"
},
{
"id": "30",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "30"
},
{
"id": "31",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "31"
},
{
"id": "32",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "32"
},
{
"id": "33",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "33"
},
{
"id": "34",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "34"
},
{
"id": "35",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "35"
},
{
"id": "36",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "36"
},
{
"id": "37",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "37"
},
{
"id": "38",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "38"
},
{
"id": "39",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "39"
},
{
"id": "40",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "40"
},
{
"id": "41",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "41"
},
{
"id": "42",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "42"
},
{
"id": "43",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "43"
},
{
"id": "44",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "44"
},
{
"id": "45",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "45"
}
],
"value": {
"amountGross": 11400000000,
"amount": 9500000000,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"lots": [
{
"id": "1",
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"status": "complete",
"title": "Lot 1 (a) - England (North) - JCT Minor Works Building Contract (MW)",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "2",
"title": "Lot 1 (b) - England (North) - JCT Intermediate Building Contract (IC)",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "3",
"title": "Lot 1 (c)- England (North) - JCT Design and Build Contract (D&B)",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "4",
"title": "Lot 1 (d) - England North - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "5",
"title": "Lot 1 (e) - England North - NEC 4 Engineering and Construction Short Contract",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "6",
"title": "Lot 1 (f) - England North - NEC4 Engineering and Construction Contract",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "7",
"title": "Lot 1 (g) - England North - NEC4 Engineering and Construction Contract with NEC4 Professional Services Contract",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "8",
"title": "Lot 1 (h) - England North - NEC4 Engineering and Construction Contract with D&B",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "9",
"title": "Lot 1 (i) - England North - National Federation of Demolition Contractors Direct Form of Contract",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "10",
"title": "Lot 2 (a) - England Midlands - JCT Minor Works Building Contract (MW)",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "11",
"title": "Lot 2 (b) - England Midlands- JCT Intermediate Building Contract (IC)",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "12",
"title": "Lot 2 (c) - England Midlands- JCT Design and Build Contract (D&B)",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "13",
"title": "Lot 2 (d) - England Midlands - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "14",
"title": "Lot 2 (e) - England Midlands - NEC 4 Engineering and Construction Short Contract",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "15",
"title": "Lot 2 (f) - England Midlands - NEC4 Engineering and Construction Contract",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "16",
"title": "Lot 2 (g) - England Midlands - NEC4 Engineering and Construction Contract with NEC4 Professional Services Contract",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "17",
"title": "Lot 2 (h) - England Midlands - NEC4 Engineering and Construction Contract with D&B",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "18",
"title": "Lot 2 (i) - England Midlands - National Federation of Demolition Contractors Direct Form of Contract",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "19",
"title": "Lot 3 (a) - England South - JCT Minor Works Building Contract (MW)",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "20",
"title": "Lot 3 (b) - England South - JCT Intermediate Building Contract (IC)",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "21",
"title": "Lot 3 (c) - England South - JCT Design and Build Contract (D&B)",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "22",
"title": "Lot 3 (d) - England South - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "23",
"title": "Lot 3 (e) - England South - NEC 4 Engineering and Construction Short Contract",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "24",
"title": "Lot 3 (f) - England South - NEC4 Engineering and Construction Contract",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "25",
"title": "Lot 3 (g) - England South - NEC4 Engineering and Construction Contract with NEC4 Professional Services Contract",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "26",
"title": "Lot 3 (h) - England South - NEC4 Engineering and Construction Contract with D&B",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "27",
"title": "Lot 3 (i) - England South - National Federation of Demolition Contractors Direct Form of Contract",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "28",
"title": "Lot 4 (a) - Wales - JCT Minor Works Building Contract (MW)",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "29",
"title": "Lot 4 (b) - Wales - JCT Intermediate Building Contract (IC)",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "30",
"title": "Lot 4 (c) - Wales - JCT Design and Build Contract (D&B)",
"status": "complete",
"value": {
"amountGross": 253333333.33,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "31",
"title": "Lot 4 (d) - Wales - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)",
"status": "complete",
"value": {
"amountGross": 253333333.34,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "32",
"title": "Lot 4 (e) - Wales - NEC 4 Engineering and Construction Short Contract",
"status": "complete",
"value": {
"amountGross": 253333333.34,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "33",
"title": "Lot 4 (f) - Wales - NEC4 Engineering and Construction Contract",
"status": "complete",
"value": {
"amountGross": 253333333.34,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "34",
"title": "Lot 4 (g) - Wales - NEC4 Engineering and Construction Contract with NEC4 Professional Services Contract",
"status": "complete",
"value": {
"amountGross": 253333333.34,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "35",
"title": "Lot 4 (h) - Wales - NEC4 Engineering and Construction Contract with D&B",
"status": "complete",
"value": {
"amountGross": 253333333.34,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "36",
"title": "Lot 4 (i) - Wales - National Federation of Demolition Contractors Direct Form of Contract",
"status": "complete",
"value": {
"amountGross": 253333333.34,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "37",
"title": "Lot 5 (a) - Scotland - JCT Minor Works Building Contract (MW)",
"status": "complete",
"value": {
"amountGross": 253333333.34,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "38",
"title": "Lot 5 (b) - Scotland - JCT Intermediate Building Contract (IC)",
"status": "complete",
"value": {
"amountGross": 253333333.34,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "39",
"title": "Lot 5 (c) - Scotland - JCT Design and Build Contract (D&B)",
"status": "complete",
"value": {
"amountGross": 253333333.34,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "40",
"title": "Lot 5 (d) - Scotland - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)",
"status": "complete",
"value": {
"amountGross": 253333333.34,
"amount": 211111111.11,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "41",
"title": "Lot 5 (e) - Scotland - NEC 4 Engineering and Construction Short Contract",
"status": "complete",
"value": {
"amountGross": 253333333.34,
"amount": 211111111.12,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "42",
"title": "Lot 5 (f) - Scotland - NEC4 Engineering and Construction Contract",
"status": "complete",
"value": {
"amountGross": 253333333.34,
"amount": 211111111.12,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "43",
"title": "Lot 5 (g) - Scotland - NEC4 Engineering and Construction Contract with NEC4 Professional Services Contract",
"status": "complete",
"value": {
"amountGross": 253333333.34,
"amount": 211111111.12,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "44",
"title": "Lot 5 (h) - Scotland - NEC4 Engineering and Construction Contract with D&B",
"status": "complete",
"value": {
"amountGross": 253333333.34,
"amount": 211111111.12,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
},
{
"id": "45",
"title": "Lot 5 (i) - Scotland - National Federation of Demolition Contractors Direct Form of Contract",
"status": "complete",
"value": {
"amountGross": 253333333.34,
"amount": 211111111.12,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "price",
"name": "Pricing",
"description": "Pricing",
"numbers": [
{
"number": 30,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Customer Requirements",
"description": "Customer Requirements",
"numbers": [
{
"number": 70,
"weight": "percentageExact"
}
]
}
]
},
"selectionCriteria": {
"criteria": [
{
"type": "economic",
"description": "Confirmed in document pack"
},
{
"type": "technical",
"description": "Confirmed in document pack"
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2026-05-01T00:00:00+01:00",
"endDate": "2028-04-30T23:59:59+01:00",
"maxExtentDate": "2034-04-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Maximum 3 extensions of 24 months per extension."
}
}
],
"communication": {
"futureNoticeDate": "2025-09-25T23:59:59+01:00"
},
"status": "complete",
"procurementMethod": "open",
"procurementMethodDetails": "Competitive flexible procedure",
"procedure": {
"features": "This procurement will be conducted using a Competitive Flexible Procedure in accordance with Section 20 of the Procurement Act 2023. The procedure has been designed to ensure compliance with the Act while providing the Contracting Authority with the flexibility required to structure a process proportionate to the subject matter and complexity of this procurement. The process will comprise multiple stages: 1. Selection Stage: Bidders will be assessed to determine whether they are excluded or excludable suppliers under the Act and whether they meet the stated conditions of participation. Following evaluation, only the ten (10) highest scoring compliant bidders per Lot will be invited to progress to the next stage. 2. Dialogue Phase: Shortlisted suppliers will be invited to engage in structured dialogue to refine aspects of the procurement, including the approach to call-off contracts (based on the NEC and JCT suites), the framework conditions and the framework fee structure. 3. Final Tender Stage: Following dialogue, the Contracting Authority may issue clarifications or amendments to the procurement documents. Bidders will then be invited to submit final tenders, which will be evaluated against published qualitative and commercial criteria. 4. Award: Contracts will be awarded to the most advantageous tenders, in accordance with Section 19 of the Procurement Act 2023. This bespoke procedure is designed to balance full compliance with the Procurement Act 2023 with a streamlined, transparent, and fair process that secures the best outcomes for both Contracting Authorities and framework suppliers."
},
"submissionMethodDetails": "To access this opportunity, log in to https://suppliers.multiquote.com and view the opportunity. If you are not registered with MultiQuote, please visit https://suppliers.multiquote.com, complete the registration form on the log in page and quote the title and reference of the notice in your registration.",
"submissionTerms": {
"electronicSubmissionPolicy": "allowed",
"languages": [
"en"
]
},
"tenderPeriod": {
"endDate": "2025-10-30T17:00:00Z"
},
"enquiryPeriod": {
"endDate": "2025-10-27T17:00:00Z"
},
"awardPeriod": {
"endDate": "2026-05-01T23:59:59+01:00"
},
"documents": [
{
"id": "conflictOfInterest",
"documentType": "conflictOfInterest",
"description": "Not published"
},
{
"id": "062263-2025",
"documentType": "tenderNotice",
"noticeType": "UK4",
"description": "Tender notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/062263-2025",
"datePublished": "2025-10-03T15:45:34+01:00",
"format": "text/html"
}
]
},
"language": "en",
"bids": {
"details": [
{
"id": "1",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PTLR-9847-LWTH",
"name": "Aptus Construction Ltd"
}
],
"relatedLots": [
"1",
"2",
"5",
"6",
"7",
"8"
]
},
{
"id": "2",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PTBP-9736-DCWD",
"name": "GLC PROJECTS LTD"
}
],
"relatedLots": [
"1",
"3",
"5",
"9",
"10",
"12",
"14",
"18",
"27",
"36",
"37",
"39",
"41",
"45"
]
},
{
"id": "3",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PBPY-4769-XNBL",
"name": "Compass Developments (NE) Ltd"
}
],
"relatedLots": [
"1",
"2",
"4",
"5"
]
},
{
"id": "4",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PHBV-8337-DNQL",
"name": "Brims Construction Ltd"
}
],
"relatedLots": [
"1",
"2",
"4",
"8"
]
},
{
"id": "5",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PTBH-4688-MMXN",
"name": "Walter Carefoot & Sons (Construction) Ltd."
}
],
"relatedLots": [
"1",
"2",
"3"
]
},
{
"id": "6",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PYRJ-3189-GLDM",
"name": "Rosslee Construction Ltd"
}
],
"relatedLots": [
"1",
"2",
"4",
"5",
"6",
"7"
]
},
{
"id": "7",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PVXV-4192-PRXH",
"name": "Senate Mech Ltd"
}
],
"relatedLots": [
"1",
"2",
"5"
]
},
{
"id": "8",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PWDD-8548-WNWN",
"name": "Whitfield & Brown (Developments) Ltd"
}
],
"relatedLots": [
"1",
"2",
"4"
]
},
{
"id": "9",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PRLW-6359-JLDP",
"name": "EFT Construction Ltd"
}
],
"relatedLots": [
"1",
"2",
"3",
"6"
]
},
{
"id": "10",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PRRH-8298-MPBM",
"name": "Seddon Construction Limited"
}
],
"relatedLots": [
"1",
"2",
"3",
"4",
"5",
"6",
"7",
"8",
"10",
"11",
"12",
"13",
"14",
"15",
"16",
"17"
]
},
{
"id": "11",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PZRH-8617-DHJT",
"name": "FRANK ROGERS (BUILDING CONTRACTOR) LIMITED"
}
],
"relatedLots": [
"1",
"2",
"3",
"6",
"8",
"12",
"21"
]
},
{
"id": "12",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PHWR-8769-WWGL",
"name": "Jupiter Construction LTD"
}
],
"relatedLots": [
"2",
"3"
]
},
{
"id": "13",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PRGP-6331-RLDT",
"name": "Willliam Birch & Sons Ltd"
}
],
"relatedLots": [
"2",
"5",
"7",
"8"
]
},
{
"id": "14",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PBRQ-1568-JRLT",
"name": "ASHFIELD PROJECTS (YORKSHIRE) LTD"
}
],
"relatedLots": [
"2",
"3"
]
},
{
"id": "15",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PRJV-5614-DHMZ",
"name": "Esh Construction Limited"
}
],
"relatedLots": [
"2",
"4",
"5",
"7",
"8"
]
},
{
"id": "16",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PZGV-6617-DMBY",
"name": "7 FORMATION LIMITED"
}
],
"relatedLots": [
"2",
"10",
"11",
"19",
"20",
"21",
"28",
"29",
"30",
"37",
"38",
"39"
]
},
{
"id": "17",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PZQD-1942-MTWY",
"name": "NRC Services Limited"
}
],
"relatedLots": [
"2",
"6"
]
},
{
"id": "18",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PGTW-4456-TGCY",
"name": "GRAHAM"
}
],
"relatedLots": [
"3",
"4",
"5",
"6",
"7",
"8",
"12",
"13",
"14",
"15",
"16",
"17",
"21",
"22",
"23",
"24",
"25",
"26",
"37",
"39",
"40",
"41",
"42",
"43",
"44"
]
},
{
"id": "19",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PQZD-6932-BDNH",
"name": "MYC Group Ltd"
}
],
"relatedLots": [
"3",
"4",
"12",
"13",
"21",
"22"
]
},
{
"id": "20",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
}
],
"relatedLots": [
"3",
"4",
"6",
"7",
"8",
"12",
"13",
"15",
"16",
"17",
"21",
"22",
"24",
"25",
"26",
"30",
"31",
"33",
"34",
"35",
"39",
"40",
"42",
"43",
"44"
]
},
{
"id": "21",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PJVM-7393-WBVP",
"name": "GALLAWAY CONSTRUCTION LIMITED"
}
],
"relatedLots": [
"4",
"8",
"10",
"11",
"13",
"14",
"15",
"17",
"28",
"29",
"30",
"31",
"32",
"33",
"35"
]
},
{
"id": "22",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PJZD-8216-PHJX",
"name": "AREA"
}
],
"relatedLots": [
"4",
"13",
"21",
"22",
"30",
"31",
"39",
"40"
]
},
{
"id": "23",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PWNL-8777-NNQX",
"name": "John Turner Construction Group Ltd"
}
],
"relatedLots": [
"5"
]
},
{
"id": "24",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PYBB-4931-GPPD",
"name": "CBES"
}
],
"relatedLots": [
"5",
"7",
"10",
"11",
"14",
"15",
"16",
"37",
"38",
"39",
"40",
"41",
"42",
"43",
"44"
]
},
{
"id": "25",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PLDN-9791-PJGH",
"name": "MBC Building Contractors"
}
],
"relatedLots": [
"5",
"9",
"10",
"11",
"14",
"18"
]
},
{
"id": "26",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PBPZ-4782-JBVH",
"name": "Premier Modular Ltd"
}
],
"relatedLots": [
"7",
"16",
"23",
"25",
"26",
"30",
"31",
"32",
"33",
"34",
"39",
"40",
"41",
"42",
"43"
]
},
{
"id": "27",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PDLR-6293-DLGH",
"name": "GMI CONSTRUCTION GROUP PLC"
}
],
"relatedLots": [
"7",
"8",
"16",
"17"
]
},
{
"id": "28",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PXDY-7891-BHYG",
"name": "RHODAR INDUSTRIAL SERVICES LIMITED"
}
],
"relatedLots": [
"9",
"18",
"27",
"36",
"45"
]
},
{
"id": "29",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PDJQ-6122-BMVY",
"name": "PLANET INTERIOR PROJECTS LIMITED"
}
],
"relatedLots": [
"9",
"11",
"15",
"18",
"28",
"29",
"30",
"31",
"32",
"33",
"34",
"35",
"36"
]
},
{
"id": "30",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PDNC-5796-MJWT",
"name": "DSM (DSM DEMOLITION LIMITED)"
}
],
"relatedLots": [
"9",
"18",
"27"
]
},
{
"id": "31",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PHJX-3544-MTVP",
"name": "A.BUCKLER HAULAGE LIMITED"
}
],
"relatedLots": [
"9"
]
},
{
"id": "32",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PPQD-9154-VBML",
"name": "A.R. CARTWRIGHT (CONSTRUCTION) LIMITED"
}
],
"relatedLots": [
"10",
"11"
]
},
{
"id": "33",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PTHJ-9659-VXHZ",
"name": "BSN Group Construction Ltd"
}
],
"relatedLots": [
"10",
"11",
"12",
"13",
"15"
]
},
{
"id": "34",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PMMH-8591-VGTY",
"name": "M & J Group (Construction & Roofing) Ltd."
}
],
"relatedLots": [
"10",
"11",
"13",
"14",
"15",
"16",
"17",
"21",
"22",
"23",
"24",
"25",
"26"
]
},
{
"id": "35",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PBXL-9667-CZWP",
"name": "VINCI Facilities"
}
],
"relatedLots": [
"10",
"23",
"25",
"28",
"29",
"31",
"32",
"33",
"34"
]
},
{
"id": "36",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PJNB-7236-ZVCQ",
"name": "M & O BUILDING CONTRACTORS LIMITED"
}
],
"relatedLots": [
"10",
"11",
"12",
"13",
"15",
"17"
]
},
{
"id": "37",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PTRJ-1317-LMRY",
"name": "Etec Group"
}
],
"relatedLots": [
"11",
"14",
"15",
"16",
"17",
"20",
"23",
"24",
"25",
"26",
"28",
"29",
"30",
"31",
"32",
"33",
"34",
"35"
]
},
{
"id": "38",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PTXD-1133-HVRW",
"name": "Maylarch Environmental Ltd"
}
],
"relatedLots": [
"18",
"27"
]
},
{
"id": "39",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PCMN-5796-PHGT",
"name": "Every Project Counts Ltd"
}
],
"relatedLots": [
"19",
"20",
"21"
]
},
{
"id": "40",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PLBB-6351-LDWL",
"name": "Standage & Co. Limited"
}
],
"relatedLots": [
"19",
"20",
"21",
"22"
]
},
{
"id": "41",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PBJZ-9979-PBMW",
"name": "Beardwell Construction Ltd"
}
],
"relatedLots": [
"19",
"20",
"21",
"22",
"23",
"24",
"26"
]
},
{
"id": "42",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PGXX-7212-MLBQ",
"name": "Carmelcrest Limited"
}
],
"relatedLots": [
"19",
"20",
"22",
"23",
"24",
"25",
"26",
"27"
]
},
{
"id": "43",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PPTX-1438-QCTR",
"name": "TOTAL PROTECTION (CONTRACTING SERVICES) LTD"
}
],
"relatedLots": [
"19",
"20"
]
},
{
"id": "44",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PDVH-1753-WZJH",
"name": "Mulalley and Company Ltd"
}
],
"relatedLots": [
"19",
"20",
"21",
"22",
"24",
"26"
]
},
{
"id": "45",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PJPB-5212-BNDP",
"name": "Beard Construction"
}
],
"relatedLots": [
"19",
"20",
"21",
"22",
"23",
"24",
"25",
"26"
]
},
{
"id": "46",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PTZX-3371-DHCD",
"name": "Knightsbridge Property Services Ltd"
}
],
"relatedLots": [
"20",
"23",
"24"
]
},
{
"id": "47",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PBTV-4868-CNJH",
"name": "C.G. FRY AND SON LIMITED"
}
],
"relatedLots": [
"20"
]
},
{
"id": "48",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PHTT-9248-ZXMG",
"name": "CITYAXIS LIMITED"
}
],
"relatedLots": [
"25",
"26"
]
},
{
"id": "49",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PBPD-9992-MNVW",
"name": "D R W LTD."
}
],
"relatedLots": [
"37",
"38",
"39",
"41",
"42",
"44"
]
},
{
"id": "50",
"status": "valid",
"tenderers": [
{
"id": "GB-PPON-PWGZ-4584-LXJJ",
"name": "CCG (SCOTLAND) LIMITED"
}
],
"relatedLots": [
"39",
"40",
"42",
"43",
"44"
]
}
],
"statistics": [
{
"id": "1",
"measure": "bids",
"value": 11,
"relatedLot": "1"
},
{
"id": "2",
"measure": "bids",
"value": 16,
"relatedLot": "2"
},
{
"id": "3",
"measure": "bids",
"value": 10,
"relatedLot": "3"
},
{
"id": "4",
"measure": "bids",
"value": 11,
"relatedLot": "4"
},
{
"id": "5",
"measure": "bids",
"value": 12,
"relatedLot": "5"
},
{
"id": "6",
"measure": "bids",
"value": 8,
"relatedLot": "6"
},
{
"id": "7",
"measure": "bids",
"value": 10,
"relatedLot": "7"
},
{
"id": "8",
"measure": "bids",
"value": 10,
"relatedLot": "8"
},
{
"id": "9",
"measure": "bids",
"value": 6,
"relatedLot": "9"
},
{
"id": "10",
"measure": "bids",
"value": 11,
"relatedLot": "10"
},
{
"id": "11",
"measure": "bids",
"value": 11,
"relatedLot": "11"
},
{
"id": "12",
"measure": "bids",
"value": 8,
"relatedLot": "12"
},
{
"id": "13",
"measure": "bids",
"value": 9,
"relatedLot": "13"
},
{
"id": "14",
"measure": "bids",
"value": 8,
"relatedLot": "14"
},
{
"id": "15",
"measure": "bids",
"value": 10,
"relatedLot": "15"
},
{
"id": "16",
"measure": "bids",
"value": 8,
"relatedLot": "16"
},
{
"id": "17",
"measure": "bids",
"value": 8,
"relatedLot": "17"
},
{
"id": "18",
"measure": "bids",
"value": 6,
"relatedLot": "18"
},
{
"id": "19",
"measure": "bids",
"value": 8,
"relatedLot": "19"
},
{
"id": "20",
"measure": "bids",
"value": 11,
"relatedLot": "20"
},
{
"id": "21",
"measure": "bids",
"value": 12,
"relatedLot": "21"
},
{
"id": "22",
"measure": "bids",
"value": 10,
"relatedLot": "22"
},
{
"id": "23",
"measure": "bids",
"value": 9,
"relatedLot": "23"
},
{
"id": "24",
"measure": "bids",
"value": 9,
"relatedLot": "24"
},
{
"id": "25",
"measure": "bids",
"value": 9,
"relatedLot": "25"
},
{
"id": "26",
"measure": "bids",
"value": 10,
"relatedLot": "26"
},
{
"id": "27",
"measure": "bids",
"value": 5,
"relatedLot": "27"
},
{
"id": "28",
"measure": "bids",
"value": 5,
"relatedLot": "28"
},
{
"id": "29",
"measure": "bids",
"value": 5,
"relatedLot": "29"
},
{
"id": "30",
"measure": "bids",
"value": 7,
"relatedLot": "30"
},
{
"id": "31",
"measure": "bids",
"value": 7,
"relatedLot": "31"
},
{
"id": "32",
"measure": "bids",
"value": 5,
"relatedLot": "32"
},
{
"id": "33",
"measure": "bids",
"value": 6,
"relatedLot": "33"
},
{
"id": "34",
"measure": "bids",
"value": 5,
"relatedLot": "34"
},
{
"id": "35",
"measure": "bids",
"value": 4,
"relatedLot": "35"
},
{
"id": "36",
"measure": "bids",
"value": 3,
"relatedLot": "36"
},
{
"id": "37",
"measure": "bids",
"value": 5,
"relatedLot": "37"
},
{
"id": "38",
"measure": "bids",
"value": 3,
"relatedLot": "38"
},
{
"id": "39",
"measure": "bids",
"value": 9,
"relatedLot": "39"
},
{
"id": "40",
"measure": "bids",
"value": 6,
"relatedLot": "40"
},
{
"id": "41",
"measure": "bids",
"value": 5,
"relatedLot": "41"
},
{
"id": "42",
"measure": "bids",
"value": 6,
"relatedLot": "42"
},
{
"id": "43",
"measure": "bids",
"value": 5,
"relatedLot": "43"
},
{
"id": "44",
"measure": "bids",
"value": 5,
"relatedLot": "44"
},
{
"id": "45",
"measure": "bids",
"value": 2,
"relatedLot": "45"
},
{
"id": "46",
"measure": "finalStageBids",
"value": 11,
"relatedLot": "1"
},
{
"id": "47",
"measure": "smeFinalStageBids",
"value": 3,
"relatedLot": "1"
},
{
"id": "48",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "1"
},
{
"id": "49",
"measure": "finalStageBids",
"value": 16,
"relatedLot": "2"
},
{
"id": "50",
"measure": "smeFinalStageBids",
"value": 3,
"relatedLot": "2"
},
{
"id": "51",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "2"
},
{
"id": "52",
"measure": "finalStageBids",
"value": 10,
"relatedLot": "3"
},
{
"id": "53",
"measure": "smeFinalStageBids",
"value": 0,
"relatedLot": "3"
},
{
"id": "54",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "3"
},
{
"id": "55",
"measure": "finalStageBids",
"value": 11,
"relatedLot": "4"
},
{
"id": "56",
"measure": "smeFinalStageBids",
"value": 2,
"relatedLot": "4"
},
{
"id": "57",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "4"
},
{
"id": "58",
"measure": "finalStageBids",
"value": 12,
"relatedLot": "5"
},
{
"id": "59",
"measure": "smeFinalStageBids",
"value": 3,
"relatedLot": "5"
},
{
"id": "60",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "5"
},
{
"id": "61",
"measure": "finalStageBids",
"value": 8,
"relatedLot": "6"
},
{
"id": "62",
"measure": "smeFinalStageBids",
"value": 2,
"relatedLot": "6"
},
{
"id": "63",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "6"
},
{
"id": "64",
"measure": "finalStageBids",
"value": 10,
"relatedLot": "7"
},
{
"id": "65",
"measure": "smeFinalStageBids",
"value": 2,
"relatedLot": "7"
},
{
"id": "66",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "7"
},
{
"id": "67",
"measure": "finalStageBids",
"value": 10,
"relatedLot": "8"
},
{
"id": "68",
"measure": "smeFinalStageBids",
"value": 1,
"relatedLot": "8"
},
{
"id": "69",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "8"
},
{
"id": "70",
"measure": "finalStageBids",
"value": 6,
"relatedLot": "9"
},
{
"id": "71",
"measure": "smeFinalStageBids",
"value": 0,
"relatedLot": "9"
},
{
"id": "72",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "9"
},
{
"id": "73",
"measure": "finalStageBids",
"value": 11,
"relatedLot": "10"
},
{
"id": "74",
"measure": "smeFinalStageBids",
"value": 0,
"relatedLot": "10"
},
{
"id": "75",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "10"
},
{
"id": "76",
"measure": "finalStageBids",
"value": 11,
"relatedLot": "11"
},
{
"id": "77",
"measure": "smeFinalStageBids",
"value": 1,
"relatedLot": "11"
},
{
"id": "78",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "11"
},
{
"id": "79",
"measure": "finalStageBids",
"value": 8,
"relatedLot": "12"
},
{
"id": "80",
"measure": "smeFinalStageBids",
"value": 0,
"relatedLot": "12"
},
{
"id": "81",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "12"
},
{
"id": "82",
"measure": "finalStageBids",
"value": 9,
"relatedLot": "13"
},
{
"id": "83",
"measure": "smeFinalStageBids",
"value": 0,
"relatedLot": "13"
},
{
"id": "84",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "13"
},
{
"id": "85",
"measure": "finalStageBids",
"value": 8,
"relatedLot": "14"
},
{
"id": "86",
"measure": "smeFinalStageBids",
"value": 1,
"relatedLot": "14"
},
{
"id": "87",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "14"
},
{
"id": "88",
"measure": "finalStageBids",
"value": 10,
"relatedLot": "15"
},
{
"id": "89",
"measure": "smeFinalStageBids",
"value": 1,
"relatedLot": "15"
},
{
"id": "90",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "15"
},
{
"id": "91",
"measure": "finalStageBids",
"value": 8,
"relatedLot": "16"
},
{
"id": "92",
"measure": "smeFinalStageBids",
"value": 1,
"relatedLot": "16"
},
{
"id": "93",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "16"
},
{
"id": "94",
"measure": "finalStageBids",
"value": 8,
"relatedLot": "17"
},
{
"id": "95",
"measure": "smeFinalStageBids",
"value": 1,
"relatedLot": "17"
},
{
"id": "96",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "17"
},
{
"id": "97",
"measure": "finalStageBids",
"value": 6,
"relatedLot": "18"
},
{
"id": "98",
"measure": "smeFinalStageBids",
"value": 1,
"relatedLot": "18"
},
{
"id": "99",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "18"
},
{
"id": "100",
"measure": "finalStageBids",
"value": 8,
"relatedLot": "19"
},
{
"id": "101",
"measure": "smeFinalStageBids",
"value": 2,
"relatedLot": "19"
},
{
"id": "102",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "19"
},
{
"id": "103",
"measure": "finalStageBids",
"value": 11,
"relatedLot": "20"
},
{
"id": "104",
"measure": "smeFinalStageBids",
"value": 3,
"relatedLot": "20"
},
{
"id": "105",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "20"
},
{
"id": "106",
"measure": "finalStageBids",
"value": 12,
"relatedLot": "21"
},
{
"id": "107",
"measure": "smeFinalStageBids",
"value": 1,
"relatedLot": "21"
},
{
"id": "108",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "21"
},
{
"id": "109",
"measure": "finalStageBids",
"value": 10,
"relatedLot": "22"
},
{
"id": "110",
"measure": "smeFinalStageBids",
"value": 1,
"relatedLot": "22"
},
{
"id": "111",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "22"
},
{
"id": "112",
"measure": "finalStageBids",
"value": 9,
"relatedLot": "23"
},
{
"id": "113",
"measure": "smeFinalStageBids",
"value": 2,
"relatedLot": "23"
},
{
"id": "114",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "23"
},
{
"id": "115",
"measure": "finalStageBids",
"value": 9,
"relatedLot": "24"
},
{
"id": "116",
"measure": "smeFinalStageBids",
"value": 2,
"relatedLot": "24"
},
{
"id": "117",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "24"
},
{
"id": "118",
"measure": "finalStageBids",
"value": 9,
"relatedLot": "25"
},
{
"id": "119",
"measure": "smeFinalStageBids",
"value": 2,
"relatedLot": "25"
},
{
"id": "120",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "25"
},
{
"id": "121",
"measure": "finalStageBids",
"value": 10,
"relatedLot": "26"
},
{
"id": "122",
"measure": "smeFinalStageBids",
"value": 2,
"relatedLot": "26"
},
{
"id": "123",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "26"
},
{
"id": "124",
"measure": "finalStageBids",
"value": 5,
"relatedLot": "27"
},
{
"id": "125",
"measure": "smeFinalStageBids",
"value": 2,
"relatedLot": "27"
},
{
"id": "126",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "27"
},
{
"id": "127",
"measure": "finalStageBids",
"value": 5,
"relatedLot": "28"
},
{
"id": "128",
"measure": "smeFinalStageBids",
"value": 1,
"relatedLot": "28"
},
{
"id": "129",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "28"
},
{
"id": "130",
"measure": "finalStageBids",
"value": 5,
"relatedLot": "29"
},
{
"id": "131",
"measure": "smeFinalStageBids",
"value": 1,
"relatedLot": "29"
},
{
"id": "132",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "29"
},
{
"id": "133",
"measure": "finalStageBids",
"value": 7,
"relatedLot": "30"
},
{
"id": "134",
"measure": "smeFinalStageBids",
"value": 1,
"relatedLot": "30"
},
{
"id": "135",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "30"
},
{
"id": "136",
"measure": "finalStageBids",
"value": 7,
"relatedLot": "31"
},
{
"id": "137",
"measure": "smeFinalStageBids",
"value": 1,
"relatedLot": "31"
},
{
"id": "138",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "31"
},
{
"id": "139",
"measure": "finalStageBids",
"value": 5,
"relatedLot": "32"
},
{
"id": "140",
"measure": "smeFinalStageBids",
"value": 1,
"relatedLot": "32"
},
{
"id": "141",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "32"
},
{
"id": "142",
"measure": "finalStageBids",
"value": 6,
"relatedLot": "33"
},
{
"id": "143",
"measure": "smeFinalStageBids",
"value": 1,
"relatedLot": "33"
},
{
"id": "144",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "33"
},
{
"id": "145",
"measure": "finalStageBids",
"value": 5,
"relatedLot": "34"
},
{
"id": "146",
"measure": "smeFinalStageBids",
"value": 1,
"relatedLot": "34"
},
{
"id": "147",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "34"
},
{
"id": "148",
"measure": "finalStageBids",
"value": 4,
"relatedLot": "35"
},
{
"id": "149",
"measure": "smeFinalStageBids",
"value": 1,
"relatedLot": "35"
},
{
"id": "150",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "35"
},
{
"id": "151",
"measure": "finalStageBids",
"value": 3,
"relatedLot": "36"
},
{
"id": "152",
"measure": "smeFinalStageBids",
"value": 0,
"relatedLot": "36"
},
{
"id": "153",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "36"
},
{
"id": "154",
"measure": "finalStageBids",
"value": 5,
"relatedLot": "37"
},
{
"id": "155",
"measure": "smeFinalStageBids",
"value": 0,
"relatedLot": "37"
},
{
"id": "156",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "37"
},
{
"id": "157",
"measure": "finalStageBids",
"value": 3,
"relatedLot": "38"
},
{
"id": "158",
"measure": "smeFinalStageBids",
"value": 0,
"relatedLot": "38"
},
{
"id": "159",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "38"
},
{
"id": "160",
"measure": "finalStageBids",
"value": 9,
"relatedLot": "39"
},
{
"id": "161",
"measure": "smeFinalStageBids",
"value": 0,
"relatedLot": "39"
},
{
"id": "162",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "39"
},
{
"id": "163",
"measure": "finalStageBids",
"value": 6,
"relatedLot": "40"
},
{
"id": "164",
"measure": "smeFinalStageBids",
"value": 0,
"relatedLot": "40"
},
{
"id": "165",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "40"
},
{
"id": "166",
"measure": "finalStageBids",
"value": 5,
"relatedLot": "41"
},
{
"id": "167",
"measure": "smeFinalStageBids",
"value": 0,
"relatedLot": "41"
},
{
"id": "168",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "41"
},
{
"id": "169",
"measure": "finalStageBids",
"value": 6,
"relatedLot": "42"
},
{
"id": "170",
"measure": "smeFinalStageBids",
"value": 0,
"relatedLot": "42"
},
{
"id": "171",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "42"
},
{
"id": "172",
"measure": "finalStageBids",
"value": 5,
"relatedLot": "43"
},
{
"id": "173",
"measure": "smeFinalStageBids",
"value": 0,
"relatedLot": "43"
},
{
"id": "174",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "43"
},
{
"id": "175",
"measure": "finalStageBids",
"value": 5,
"relatedLot": "44"
},
{
"id": "176",
"measure": "smeFinalStageBids",
"value": 0,
"relatedLot": "44"
},
{
"id": "177",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "44"
},
{
"id": "178",
"measure": "finalStageBids",
"value": 2,
"relatedLot": "45"
},
{
"id": "179",
"measure": "smeFinalStageBids",
"value": 0,
"relatedLot": "45"
},
{
"id": "180",
"measure": "vcseFinalStageBids",
"value": 0,
"relatedLot": "45"
}
]
},
"awards": [
{
"id": "1",
"title": "Lot: (1) Lot 1 (a) - England (North) - JCT Minor Works Building Contract (MW)",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PRRH-8298-MPBM",
"name": "Seddon Construction Limited"
},
{
"id": "GB-PPON-PTBH-4688-MMXN",
"name": "Walter Carefoot & Sons (Construction) Ltd."
},
{
"id": "GB-PPON-PRLW-6359-JLDP",
"name": "EFT Construction Ltd"
},
{
"id": "GB-PPON-PVXV-4192-PRXH",
"name": "Senate Mech Ltd"
},
{
"id": "GB-PPON-PWDD-8548-WNWN",
"name": "Whitfield & Brown (Developments) Ltd"
},
{
"id": "GB-PPON-PTLR-9847-LWTH",
"name": "Aptus Construction Ltd"
}
],
"items": [
{
"id": "1",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "1"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"1"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "2",
"title": "Lot: (2) Lot 1 (b) - England (North) - JCT Intermediate Building Contract (IC)",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PRRH-8298-MPBM",
"name": "Seddon Construction Limited"
},
{
"id": "GB-PPON-PWDD-8548-WNWN",
"name": "Whitfield & Brown (Developments) Ltd"
},
{
"id": "GB-PPON-PZRH-8617-DHJT",
"name": "FRANK ROGERS (BUILDING CONTRACTOR) LIMITED"
},
{
"id": "GB-PPON-PTBH-4688-MMXN",
"name": "Walter Carefoot & Sons (Construction) Ltd."
},
{
"id": "GB-PPON-PRJV-5614-DHMZ",
"name": "Esh Construction Limited"
},
{
"id": "GB-PPON-PTLR-9847-LWTH",
"name": "Aptus Construction Ltd"
}
],
"items": [
{
"id": "2",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "2"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"2"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "3",
"title": "Lot: (3) Lot 1 (c)- England (North) - JCT Design and Build Contract (D&B)",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.5,
"amount": 211111110.5,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PTBH-4688-MMXN",
"name": "Walter Carefoot & Sons (Construction) Ltd."
},
{
"id": "GB-PPON-PZRH-8617-DHJT",
"name": "FRANK ROGERS (BUILDING CONTRACTOR) LIMITED"
},
{
"id": "GB-PPON-PRRH-8298-MPBM",
"name": "Seddon Construction Limited"
},
{
"id": "GB-PPON-PBRQ-1568-JRLT",
"name": "ASHFIELD PROJECTS (YORKSHIRE) LTD"
},
{
"id": "GB-PPON-PGTW-4456-TGCY",
"name": "GRAHAM"
},
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
}
],
"items": [
{
"id": "3",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "3"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"3"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "4",
"title": "Lot: (4) Lot 1 (d) - England North - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PWDD-8548-WNWN",
"name": "Whitfield & Brown (Developments) Ltd"
},
{
"id": "GB-PPON-PRRH-8298-MPBM",
"name": "Seddon Construction Limited"
},
{
"id": "GB-PPON-PBPY-4769-XNBL",
"name": "Compass Developments (NE) Ltd"
},
{
"id": "GB-PPON-PRJV-5614-DHMZ",
"name": "Esh Construction Limited"
},
{
"id": "GB-PPON-PGTW-4456-TGCY",
"name": "GRAHAM"
},
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
}
],
"items": [
{
"id": "4",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "4"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"4"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "5",
"title": "Lot: (5) Lot 1 (e) - England North - NEC 4 Engineering and Construction Short Contract",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PRRH-8298-MPBM",
"name": "Seddon Construction Limited"
},
{
"id": "GB-PPON-PBPY-4769-XNBL",
"name": "Compass Developments (NE) Ltd"
},
{
"id": "GB-PPON-PVXV-4192-PRXH",
"name": "Senate Mech Ltd"
},
{
"id": "GB-PPON-PRJV-5614-DHMZ",
"name": "Esh Construction Limited"
},
{
"id": "GB-PPON-PTLR-9847-LWTH",
"name": "Aptus Construction Ltd"
},
{
"id": "GB-PPON-PYBB-4931-GPPD",
"name": "CBES"
}
],
"items": [
{
"id": "5",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "5"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"5"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "6",
"title": "Lot: (6) Lot 1 (f) - England North - NEC4 Engineering and Construction Contract",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PTLR-9847-LWTH",
"name": "Aptus Construction Ltd"
},
{
"id": "GB-PPON-PRRH-8298-MPBM",
"name": "Seddon Construction Limited"
},
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
},
{
"id": "GB-PPON-PGTW-4456-TGCY",
"name": "GRAHAM"
},
{
"id": "GB-PPON-PRLW-6359-JLDP",
"name": "EFT Construction Ltd"
},
{
"id": "GB-PPON-PZRH-8617-DHJT",
"name": "FRANK ROGERS (BUILDING CONTRACTOR) LIMITED"
}
],
"items": [
{
"id": "6",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "6"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"6"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "7",
"title": "Lot: (7) Lot 1 (g) - England North - NEC4 Engineering and Construction Contract with NEC4 Professional Services Contract",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PRRH-8298-MPBM",
"name": "Seddon Construction Limited"
},
{
"id": "GB-PPON-PRJV-5614-DHMZ",
"name": "Esh Construction Limited"
},
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
},
{
"id": "GB-PPON-PYBB-4931-GPPD",
"name": "CBES"
},
{
"id": "GB-PPON-PTLR-9847-LWTH",
"name": "Aptus Construction Ltd"
},
{
"id": "GB-PPON-PDLR-6293-DLGH",
"name": "GMI CONSTRUCTION GROUP PLC"
}
],
"items": [
{
"id": "7",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "7"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"7"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "8",
"title": "Lot: (8) Lot 1 (h) - England North - NEC4 Engineering and Construction Contract with D&B",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PZRH-8617-DHJT",
"name": "FRANK ROGERS (BUILDING CONTRACTOR) LIMITED"
},
{
"id": "GB-PPON-PRJV-5614-DHMZ",
"name": "Esh Construction Limited"
},
{
"id": "GB-PPON-PTLR-9847-LWTH",
"name": "Aptus Construction Ltd"
},
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
},
{
"id": "GB-PPON-PRRH-8298-MPBM",
"name": "Seddon Construction Limited"
},
{
"id": "GB-PPON-PDLR-6293-DLGH",
"name": "GMI CONSTRUCTION GROUP PLC"
}
],
"items": [
{
"id": "8",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "8"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"8"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "9",
"title": "Lot: (9) Lot 1 (i) - England North - National Federation of Demolition Contractors Direct Form of Contract",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110,
"amount": 211111110,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PXDY-7891-BHYG",
"name": "RHODAR INDUSTRIAL SERVICES LIMITED"
},
{
"id": "GB-PPON-PHJX-3544-MTVP",
"name": "A.BUCKLER HAULAGE LIMITED"
},
{
"id": "GB-PPON-PLDN-9791-PJGH",
"name": "MBC Building Contractors"
},
{
"id": "GB-PPON-PTBP-9736-DCWD",
"name": "GLC PROJECTS LTD"
},
{
"id": "GB-PPON-PDNC-5796-MJWT",
"name": "DSM (DSM DEMOLITION LIMITED)"
}
],
"items": [
{
"id": "9",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "9"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"9"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "10",
"title": "Lot: (10) Lot 2 (a) - England Midlands - JCT Minor Works Building Contract (MW)",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PZGV-6617-DMBY",
"name": "7 FORMATION LIMITED"
},
{
"id": "GB-PPON-PTHJ-9659-VXHZ",
"name": "BSN Group Construction Ltd"
},
{
"id": "GB-PPON-PJVM-7393-WBVP",
"name": "GALLAWAY CONSTRUCTION LIMITED"
},
{
"id": "GB-PPON-PBXL-9667-CZWP",
"name": "VINCI Facilities"
},
{
"id": "GB-PPON-PRRH-8298-MPBM",
"name": "Seddon Construction Limited"
},
{
"id": "GB-PPON-PYBB-4931-GPPD",
"name": "CBES"
}
],
"items": [
{
"id": "10",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "10"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"10"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "11",
"title": "Lot: (11) Lot 2 (b) - England Midlands- JCT Intermediate Building Contract (IC)",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PTRJ-1317-LMRY",
"name": "Etec Group"
},
{
"id": "GB-PPON-PMMH-8591-VGTY",
"name": "M & J Group (Construction & Roofing) Ltd."
},
{
"id": "GB-PPON-PYBB-4931-GPPD",
"name": "CBES"
},
{
"id": "GB-PPON-PRRH-8298-MPBM",
"name": "Seddon Construction Limited"
},
{
"id": "GB-PPON-PTHJ-9659-VXHZ",
"name": "BSN Group Construction Ltd"
},
{
"id": "GB-PPON-PLDN-9791-PJGH",
"name": "MBC Building Contractors"
}
],
"items": [
{
"id": "11",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "11"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"11"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "12",
"title": "Lot: (12) Lot 2 (c) - England Midlands- JCT Design and Build Contract (D&B)",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
},
{
"id": "GB-PPON-PTHJ-9659-VXHZ",
"name": "BSN Group Construction Ltd"
},
{
"id": "GB-PPON-PQZD-6932-BDNH",
"name": "MYC Group Ltd"
},
{
"id": "GB-PPON-PJNB-7236-ZVCQ",
"name": "M & O BUILDING CONTRACTORS LIMITED"
},
{
"id": "GB-PPON-PRRH-8298-MPBM",
"name": "Seddon Construction Limited"
},
{
"id": "GB-PPON-PGTW-4456-TGCY",
"name": "GRAHAM"
}
],
"items": [
{
"id": "12",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "12"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"12"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "13",
"title": "Lot: (13) Lot 2 (d) - England Midlands - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PJVM-7393-WBVP",
"name": "GALLAWAY CONSTRUCTION LIMITED"
},
{
"id": "GB-PPON-PGTW-4456-TGCY",
"name": "GRAHAM"
},
{
"id": "GB-PPON-PTHJ-9659-VXHZ",
"name": "BSN Group Construction Ltd"
},
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
},
{
"id": "GB-PPON-PRRH-8298-MPBM",
"name": "Seddon Construction Limited"
},
{
"id": "GB-PPON-PMMH-8591-VGTY",
"name": "M & J Group (Construction & Roofing) Ltd."
}
],
"items": [
{
"id": "13",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "13"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"13"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "14",
"title": "Lot: (14) Lot 2 (e) - England Midlands - NEC 4 Engineering and Construction Short Contract",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PJVM-7393-WBVP",
"name": "GALLAWAY CONSTRUCTION LIMITED"
},
{
"id": "GB-PPON-PRRH-8298-MPBM",
"name": "Seddon Construction Limited"
},
{
"id": "GB-PPON-PYBB-4931-GPPD",
"name": "CBES"
},
{
"id": "GB-PPON-PMMH-8591-VGTY",
"name": "M & J Group (Construction & Roofing) Ltd."
},
{
"id": "GB-PPON-PLDN-9791-PJGH",
"name": "MBC Building Contractors"
},
{
"id": "GB-PPON-PGTW-4456-TGCY",
"name": "GRAHAM"
}
],
"items": [
{
"id": "14",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "14"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"14"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "15",
"title": "Lot: (15) Lot 2 (f) - England Midlands - NEC4 Engineering and Construction Contract",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PGTW-4456-TGCY",
"name": "GRAHAM"
},
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
},
{
"id": "GB-PPON-PYBB-4931-GPPD",
"name": "CBES"
},
{
"id": "GB-PPON-PTHJ-9659-VXHZ",
"name": "BSN Group Construction Ltd"
},
{
"id": "GB-PPON-PRRH-8298-MPBM",
"name": "Seddon Construction Limited"
},
{
"id": "GB-PPON-PMMH-8591-VGTY",
"name": "M & J Group (Construction & Roofing) Ltd."
}
],
"items": [
{
"id": "15",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "15"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"15"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "16",
"title": "Lot: (16) Lot 2 (g) - England Midlands - NEC4 Engineering and Construction Contract with NEC4 Professional Services Contract",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PYBB-4931-GPPD",
"name": "CBES"
},
{
"id": "GB-PPON-PRRH-8298-MPBM",
"name": "Seddon Construction Limited"
},
{
"id": "GB-PPON-PDLR-6293-DLGH",
"name": "GMI CONSTRUCTION GROUP PLC"
},
{
"id": "GB-PPON-PGTW-4456-TGCY",
"name": "GRAHAM"
},
{
"id": "GB-PPON-PMMH-8591-VGTY",
"name": "M & J Group (Construction & Roofing) Ltd."
},
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
}
],
"items": [
{
"id": "16",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "16"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"16"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "17",
"title": "Lot: (17) Lot 2 (h) - England Midlands - NEC4 Engineering and Construction Contract with D&B",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
},
{
"id": "GB-PPON-PGTW-4456-TGCY",
"name": "GRAHAM"
},
{
"id": "GB-PPON-PMMH-8591-VGTY",
"name": "M & J Group (Construction & Roofing) Ltd."
},
{
"id": "GB-PPON-PRRH-8298-MPBM",
"name": "Seddon Construction Limited"
},
{
"id": "GB-PPON-PTRJ-1317-LMRY",
"name": "Etec Group"
},
{
"id": "GB-PPON-PDLR-6293-DLGH",
"name": "GMI CONSTRUCTION GROUP PLC"
},
{
"id": "GB-PPON-PJVM-7393-WBVP",
"name": "GALLAWAY CONSTRUCTION LIMITED"
}
],
"items": [
{
"id": "17",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "17"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"17"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "18",
"title": "Lot: (18) Lot 2 (i) - England Midlands - National Federation of Demolition Contractors Direct Form of Contract",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110,
"amount": 211111110,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PXDY-7891-BHYG",
"name": "RHODAR INDUSTRIAL SERVICES LIMITED"
},
{
"id": "GB-PPON-PLDN-9791-PJGH",
"name": "MBC Building Contractors"
},
{
"id": "GB-PPON-PTBP-9736-DCWD",
"name": "GLC PROJECTS LTD"
},
{
"id": "GB-PPON-PDNC-5796-MJWT",
"name": "DSM (DSM DEMOLITION LIMITED)"
},
{
"id": "GB-PPON-PTXD-1133-HVRW",
"name": "Maylarch Environmental Ltd"
}
],
"items": [
{
"id": "18",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "18"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"18"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "19",
"title": "Lot: (19) Lot 3 (a) - England South - JCT Minor Works Building Contract (MW)",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PDVH-1753-WZJH",
"name": "Mulalley and Company Ltd"
},
{
"id": "GB-PPON-PJPB-5212-BNDP",
"name": "Beard Construction"
},
{
"id": "GB-PPON-PBJZ-9979-PBMW",
"name": "Beardwell Construction Ltd"
},
{
"id": "GB-PPON-PCMN-5796-PHGT",
"name": "Every Project Counts Ltd"
},
{
"id": "GB-PPON-PGXX-7212-MLBQ",
"name": "Carmelcrest Limited"
},
{
"id": "GB-PPON-PZGV-6617-DMBY",
"name": "7 FORMATION LIMITED"
}
],
"items": [
{
"id": "19",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "19"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"19"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "20",
"title": "Lot: (20) Lot 3 (b) - England South - JCT Intermediate Building Contract (IC)",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PTRJ-1317-LMRY",
"name": "Etec Group"
},
{
"id": "GB-PPON-PGXX-7212-MLBQ",
"name": "Carmelcrest Limited"
},
{
"id": "GB-PPON-PTZX-3371-DHCD",
"name": "Knightsbridge Property Services Ltd"
},
{
"id": "GB-PPON-PJPB-5212-BNDP",
"name": "Beard Construction"
},
{
"id": "GB-PPON-PBJZ-9979-PBMW",
"name": "Beardwell Construction Ltd"
},
{
"id": "GB-PPON-PDVH-1753-WZJH",
"name": "Mulalley and Company Ltd"
}
],
"items": [
{
"id": "20",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "20"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"20"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "21",
"title": "Lot: (21) Lot 3 (c) - England South - JCT Design and Build Contract (D&B)",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PGTW-4456-TGCY",
"name": "GRAHAM"
},
{
"id": "GB-PPON-PMMH-8591-VGTY",
"name": "M & J Group (Construction & Roofing) Ltd."
},
{
"id": "GB-PPON-PDVH-1753-WZJH",
"name": "Mulalley and Company Ltd"
},
{
"id": "GB-PPON-PBJZ-9979-PBMW",
"name": "Beardwell Construction Ltd"
},
{
"id": "GB-PPON-PJPB-5212-BNDP",
"name": "Beard Construction"
},
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
}
],
"items": [
{
"id": "21",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "21"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"21"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "22",
"title": "Lot: (22) Lot 3 (d) - England South - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PGTW-4456-TGCY",
"name": "GRAHAM"
},
{
"id": "GB-PPON-PDVH-1753-WZJH",
"name": "Mulalley and Company Ltd"
},
{
"id": "GB-PPON-PMMH-8591-VGTY",
"name": "M & J Group (Construction & Roofing) Ltd."
},
{
"id": "GB-PPON-PJPB-5212-BNDP",
"name": "Beard Construction"
},
{
"id": "GB-PPON-PBJZ-9979-PBMW",
"name": "Beardwell Construction Ltd"
},
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
}
],
"items": [
{
"id": "22",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "22"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"22"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "23",
"title": "Lot: (23) Lot 3 (e) - England South - NEC 4 Engineering and Construction Short Contract",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PBJZ-9979-PBMW",
"name": "Beardwell Construction Ltd"
},
{
"id": "GB-PPON-PGXX-7212-MLBQ",
"name": "Carmelcrest Limited"
},
{
"id": "GB-PPON-PMMH-8591-VGTY",
"name": "M & J Group (Construction & Roofing) Ltd."
},
{
"id": "GB-PPON-PBXL-9667-CZWP",
"name": "VINCI Facilities"
},
{
"id": "GB-PPON-PTZX-3371-DHCD",
"name": "Knightsbridge Property Services Ltd"
},
{
"id": "GB-PPON-PJPB-5212-BNDP",
"name": "Beard Construction"
}
],
"items": [
{
"id": "23",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "23"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"23"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "24",
"title": "Lot: (24) Lot 3 (f) - England South - NEC4 Engineering and Construction Contract",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PTZX-3371-DHCD",
"name": "Knightsbridge Property Services Ltd"
},
{
"id": "GB-PPON-PGXX-7212-MLBQ",
"name": "Carmelcrest Limited"
},
{
"id": "GB-PPON-PGTW-4456-TGCY",
"name": "GRAHAM"
},
{
"id": "GB-PPON-PJPB-5212-BNDP",
"name": "Beard Construction"
},
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
},
{
"id": "GB-PPON-PBJZ-9979-PBMW",
"name": "Beardwell Construction Ltd"
}
],
"items": [
{
"id": "24",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "24"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"24"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "25",
"title": "Lot: (25) Lot 3 (g) - England South - NEC4 Engineering and Construction Contract with NEC4 Professional Services Contract",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PGXX-7212-MLBQ",
"name": "Carmelcrest Limited"
},
{
"id": "GB-PPON-PHTT-9248-ZXMG",
"name": "CITYAXIS LIMITED"
},
{
"id": "GB-PPON-PJPB-5212-BNDP",
"name": "Beard Construction"
},
{
"id": "GB-PPON-PMMH-8591-VGTY",
"name": "M & J Group (Construction & Roofing) Ltd."
},
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
},
{
"id": "GB-PPON-PBXL-9667-CZWP",
"name": "VINCI Facilities"
}
],
"items": [
{
"id": "25",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "25"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"25"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "26",
"title": "Lot: (26) Lot 3 (h) - England South - NEC4 Engineering and Construction Contract with D&B",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PJPB-5212-BNDP",
"name": "Beard Construction"
},
{
"id": "GB-PPON-PBJZ-9979-PBMW",
"name": "Beardwell Construction Ltd"
},
{
"id": "GB-PPON-PMMH-8591-VGTY",
"name": "M & J Group (Construction & Roofing) Ltd."
},
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
},
{
"id": "GB-PPON-PGTW-4456-TGCY",
"name": "GRAHAM"
},
{
"id": "GB-PPON-PGXX-7212-MLBQ",
"name": "Carmelcrest Limited"
}
],
"items": [
{
"id": "26",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "26"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"26"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "27",
"title": "Lot: (27) Lot 3 (i) - England South - National Federation of Demolition Contractors Direct Form of Contract",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110,
"amount": 211111110,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PTBP-9736-DCWD",
"name": "GLC PROJECTS LTD"
},
{
"id": "GB-PPON-PXDY-7891-BHYG",
"name": "RHODAR INDUSTRIAL SERVICES LIMITED"
},
{
"id": "GB-PPON-PTXD-1133-HVRW",
"name": "Maylarch Environmental Ltd"
},
{
"id": "GB-PPON-PDNC-5796-MJWT",
"name": "DSM (DSM DEMOLITION LIMITED)"
},
{
"id": "GB-PPON-PGXX-7212-MLBQ",
"name": "Carmelcrest Limited"
}
],
"items": [
{
"id": "27",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "27"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"27"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "28",
"title": "Lot: (28) Lot 4 (a) - Wales - JCT Minor Works Building Contract (MW)",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.8,
"amount": 211111110.8,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PJVM-7393-WBVP",
"name": "GALLAWAY CONSTRUCTION LIMITED"
},
{
"id": "GB-PPON-PZGV-6617-DMBY",
"name": "7 FORMATION LIMITED"
},
{
"id": "GB-PPON-PBXL-9667-CZWP",
"name": "VINCI Facilities"
},
{
"id": "GB-PPON-PTRJ-1317-LMRY",
"name": "Etec Group"
}
],
"items": [
{
"id": "28",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "28"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"28"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "29",
"title": "Lot: (29) Lot 4 (b) - Wales - JCT Intermediate Building Contract (IC)",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.8,
"amount": 211111110.8,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PJVM-7393-WBVP",
"name": "GALLAWAY CONSTRUCTION LIMITED"
},
{
"id": "GB-PPON-PBXL-9667-CZWP",
"name": "VINCI Facilities"
},
{
"id": "GB-PPON-PTRJ-1317-LMRY",
"name": "Etec Group"
},
{
"id": "GB-PPON-PZGV-6617-DMBY",
"name": "7 FORMATION LIMITED"
}
],
"items": [
{
"id": "29",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "29"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"29"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "30",
"title": "Lot: (30) Lot 4 (c) - Wales - JCT Design and Build Contract (D&B)",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PTRJ-1317-LMRY",
"name": "Etec Group"
},
{
"id": "GB-PPON-PZGV-6617-DMBY",
"name": "7 FORMATION LIMITED"
},
{
"id": "GB-PPON-PJVM-7393-WBVP",
"name": "GALLAWAY CONSTRUCTION LIMITED"
},
{
"id": "GB-PPON-PJZD-8216-PHJX",
"name": "AREA"
},
{
"id": "GB-PPON-PBPZ-4782-JBVH",
"name": "Premier Modular Ltd"
},
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
}
],
"items": [
{
"id": "30",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "30"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"30"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "31",
"title": "Lot: (31) Lot 4 (d) - Wales - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PBPZ-4782-JBVH",
"name": "Premier Modular Ltd"
},
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
},
{
"id": "GB-PPON-PJVM-7393-WBVP",
"name": "GALLAWAY CONSTRUCTION LIMITED"
},
{
"id": "GB-PPON-PJZD-8216-PHJX",
"name": "AREA"
},
{
"id": "GB-PPON-PTRJ-1317-LMRY",
"name": "Etec Group"
},
{
"id": "GB-PPON-PBXL-9667-CZWP",
"name": "VINCI Facilities"
}
],
"items": [
{
"id": "31",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "31"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"31"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "32",
"title": "Lot: (32) Lot 4 (e) - Wales - NEC 4 Engineering and Construction Short Contract",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.8,
"amount": 211111110.8,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PBXL-9667-CZWP",
"name": "VINCI Facilities"
},
{
"id": "GB-PPON-PBPZ-4782-JBVH",
"name": "Premier Modular Ltd"
},
{
"id": "GB-PPON-PJVM-7393-WBVP",
"name": "GALLAWAY CONSTRUCTION LIMITED"
},
{
"id": "GB-PPON-PTRJ-1317-LMRY",
"name": "Etec Group"
}
],
"items": [
{
"id": "32",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "32"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"32"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "33",
"title": "Lot: (33) Lot 4 (f) - Wales - NEC4 Engineering and Construction Contract",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110,
"amount": 211111110,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
},
{
"id": "GB-PPON-PBXL-9667-CZWP",
"name": "VINCI Facilities"
},
{
"id": "GB-PPON-PJVM-7393-WBVP",
"name": "GALLAWAY CONSTRUCTION LIMITED"
},
{
"id": "GB-PPON-PTRJ-1317-LMRY",
"name": "Etec Group"
},
{
"id": "GB-PPON-PBPZ-4782-JBVH",
"name": "Premier Modular Ltd"
}
],
"items": [
{
"id": "33",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "33"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"33"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "34",
"title": "Lot: (34) Lot 4 (g) - Wales - NEC4 Engineering and Construction Contract with NEC4 Professional Services Contract",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.8,
"amount": 211111110.8,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
},
{
"id": "GB-PPON-PBXL-9667-CZWP",
"name": "VINCI Facilities"
},
{
"id": "GB-PPON-PBPZ-4782-JBVH",
"name": "Premier Modular Ltd"
},
{
"id": "GB-PPON-PTRJ-1317-LMRY",
"name": "Etec Group"
}
],
"items": [
{
"id": "34",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "34"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"34"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "35",
"title": "Lot: (35) Lot 4 (h) - Wales - NEC4 Engineering and Construction Contract with D&B",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.9,
"amount": 211111110.9,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
},
{
"id": "GB-PPON-PJVM-7393-WBVP",
"name": "GALLAWAY CONSTRUCTION LIMITED"
},
{
"id": "GB-PPON-PTRJ-1317-LMRY",
"name": "Etec Group"
}
],
"items": [
{
"id": "35",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "35"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"35"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "36",
"title": "Lot: (36) Lot 4 (i) - Wales - National Federation of Demolition Contractors Direct Form of Contract",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.9,
"amount": 211111110.9,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PXDY-7891-BHYG",
"name": "RHODAR INDUSTRIAL SERVICES LIMITED"
},
{
"id": "GB-PPON-PDJQ-6122-BMVY",
"name": "PLANET INTERIOR PROJECTS LIMITED"
},
{
"id": "GB-PPON-PTBP-9736-DCWD",
"name": "GLC PROJECTS LTD"
}
],
"items": [
{
"id": "36",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "36"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"36"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "37",
"title": "Lot: (37) Lot 5 (a) - Scotland - JCT Minor Works Building Contract (MW)",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110,
"amount": 211111110,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PGTW-4456-TGCY",
"name": "GRAHAM"
},
{
"id": "GB-PPON-PTBP-9736-DCWD",
"name": "GLC PROJECTS LTD"
},
{
"id": "GB-PPON-PYBB-4931-GPPD",
"name": "CBES"
},
{
"id": "GB-PPON-PBPD-9992-MNVW",
"name": "D R W LTD."
},
{
"id": "GB-PPON-PZGV-6617-DMBY",
"name": "7 FORMATION LIMITED"
}
],
"items": [
{
"id": "37",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "37"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"37"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "38",
"title": "Lot: (38) Lot 5 (b) - Scotland - JCT Intermediate Building Contract (IC)",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.9,
"amount": 211111110.9,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PBPD-9992-MNVW",
"name": "D R W LTD."
},
{
"id": "GB-PPON-PYBB-4931-GPPD",
"name": "CBES"
},
{
"id": "GB-PPON-PZGV-6617-DMBY",
"name": "7 FORMATION LIMITED"
}
],
"items": [
{
"id": "38",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "38"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"38"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "39",
"title": "Lot: (39) Lot 5 (c) - Scotland - JCT Design and Build Contract (D&B)",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PGTW-4456-TGCY",
"name": "GRAHAM"
},
{
"id": "GB-PPON-PJZD-8216-PHJX",
"name": "AREA"
},
{
"id": "GB-PPON-PWGZ-4584-LXJJ",
"name": "CCG (SCOTLAND) LIMITED"
},
{
"id": "GB-PPON-PZGV-6617-DMBY",
"name": "7 FORMATION LIMITED"
},
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
},
{
"id": "GB-PPON-PYBB-4931-GPPD",
"name": "CBES"
}
],
"items": [
{
"id": "39",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "39"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"39"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "40",
"title": "Lot: (40) Lot 5 (d) - Scotland - JCT Design & Build (D&B) with Pre-Construction Services Agreement (PCSA)",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PYBB-4931-GPPD",
"name": "CBES"
},
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
},
{
"id": "GB-PPON-PBPZ-4782-JBVH",
"name": "Premier Modular Ltd"
},
{
"id": "GB-PPON-PJZD-8216-PHJX",
"name": "AREA"
},
{
"id": "GB-PPON-PWGZ-4584-LXJJ",
"name": "CCG (SCOTLAND) LIMITED"
},
{
"id": "GB-PPON-PGTW-4456-TGCY",
"name": "GRAHAM"
}
],
"items": [
{
"id": "40",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "40"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"40"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "41",
"title": "Lot: (41) Lot 5 (e) - Scotland - NEC 4 Engineering and Construction Short Contract",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110,
"amount": 211111110,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PBPD-9992-MNVW",
"name": "D R W LTD."
},
{
"id": "GB-PPON-PTBP-9736-DCWD",
"name": "GLC PROJECTS LTD"
},
{
"id": "GB-PPON-PYBB-4931-GPPD",
"name": "CBES"
},
{
"id": "GB-PPON-PBPZ-4782-JBVH",
"name": "Premier Modular Ltd"
},
{
"id": "GB-PPON-PGTW-4456-TGCY",
"name": "GRAHAM"
}
],
"items": [
{
"id": "41",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "41"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"41"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "42",
"title": "Lot: (42) Lot 5 (f) - Scotland - NEC4 Engineering and Construction Contract",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110.6,
"amount": 211111110.6,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PBPD-9992-MNVW",
"name": "D R W LTD."
},
{
"id": "GB-PPON-PBPZ-4782-JBVH",
"name": "Premier Modular Ltd"
},
{
"id": "GB-PPON-PGTW-4456-TGCY",
"name": "GRAHAM"
},
{
"id": "GB-PPON-PYBB-4931-GPPD",
"name": "CBES"
},
{
"id": "GB-PPON-PWGZ-4584-LXJJ",
"name": "CCG (SCOTLAND) LIMITED"
},
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
}
],
"items": [
{
"id": "42",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "42"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"42"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "43",
"title": "Lot: (43) Lot 5 (g) - Scotland - NEC4 Engineering and Construction Contract with NEC4 Professional Services Contract",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110,
"amount": 211111110,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PYBB-4931-GPPD",
"name": "CBES"
},
{
"id": "GB-PPON-PGTW-4456-TGCY",
"name": "GRAHAM"
},
{
"id": "GB-PPON-PBPZ-4782-JBVH",
"name": "Premier Modular Ltd"
},
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
},
{
"id": "GB-PPON-PWGZ-4584-LXJJ",
"name": "CCG (SCOTLAND) LIMITED"
}
],
"items": [
{
"id": "43",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "43"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"43"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "44",
"title": "Lot: (44) Lot 5 (h) - Scotland - NEC4 Engineering and Construction Contract with D&B",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110,
"amount": 211111110,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PWGZ-4584-LXJJ",
"name": "CCG (SCOTLAND) LIMITED"
},
{
"id": "GB-PPON-PYBB-4931-GPPD",
"name": "CBES"
},
{
"id": "GB-PPON-PBPD-9992-MNVW",
"name": "D R W LTD."
},
{
"id": "GB-PPON-PYQH-7266-GDPX",
"name": "Galliford Try Construction Limited"
},
{
"id": "GB-PPON-PGTW-4456-TGCY",
"name": "GRAHAM"
}
],
"items": [
{
"id": "44",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "44"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"44"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
},
{
"id": "45",
"title": "Lot: (45) Lot 5 (i) - Scotland - National Federation of Demolition Contractors Direct Form of Contract",
"status": "active",
"date": "2026-06-03T00:00:00+01:00",
"value": {
"amountGross": 211111110,
"amount": 211111110,
"currency": "GBP"
},
"mainProcurementCategory": "works",
"aboveThreshold": true,
"suppliers": [
{
"id": "GB-PPON-PTBP-9736-DCWD",
"name": "GLC PROJECTS LTD"
},
{
"id": "GB-PPON-PXDY-7891-BHYG",
"name": "RHODAR INDUSTRIAL SERVICES LIMITED"
}
],
"items": [
{
"id": "45",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
}
],
"relatedLot": "45"
}
],
"contractPeriod": {
"startDate": "2026-07-01T00:00:00+01:00",
"endDate": "2028-06-30T23:59:59+01:00",
"maxExtentDate": "2034-06-30T23:59:59+01:00"
},
"hasRenewal": true,
"renewal": {
"description": "Extensions allowed: Yes (3 x 24 months)"
},
"relatedLots": [
"45"
],
"documents": [
{
"id": "055823-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/055823-2026",
"datePublished": "2026-06-12T15:42:45+01:00",
"format": "text/html"
},
{
"id": "058002-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/058002-2026",
"datePublished": "2026-06-19T12:15:25+01:00",
"format": "text/html"
},
{
"id": "059699-2026",
"documentType": "awardNotice",
"noticeType": "UK6",
"description": "Contract award notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/059699-2026",
"datePublished": "2026-06-25T10:18:19+01:00",
"format": "text/html"
}
],
"assessmentSummariesDateSent": "2026-06-03T00:00:00+01:00",
"milestones": [
{
"id": "1",
"type": "futureSignatureDate",
"dueDate": "2026-06-30T23:59:59+01:00",
"status": "scheduled"
}
]
}
]
}