Burrell Renaissance Construction Project

{
    "tag": [
        "compiled"
    ],
    "id": "ocds-r6ebe6-0000491544-2018-02-09T00:00:00Z",
    "date": "2018-02-09T00:00:00Z",
    "ocid": "ocds-r6ebe6-0000491544",
    "initiationType": "tender",
    "parties": [
        {
            "id": "org-18",
            "name": "Glasgow City Council",
            "identifier": {
                "legalName": "Glasgow City Council"
            },
            "address": {
                "streetAddress": "Chief Executives Department, City Chambers",
                "locality": "Glasgow",
                "region": "UKM34",
                "postalCode": "G2 1DU"
            },
            "contactPoint": {
                "email": "kim.mackenzie@ced.glasgow.gov.uk",
                "telephone": "+44 1412876448",
                "url": "http://www.publictendersscotland.gov.uk"
            },
            "roles": [
                "buyer",
                "reviewBody"
            ],
            "details": {
                "classifications": [
                    {
                        "id": "Regional or local authority",
                        "scheme": "TED_CA_TYPE"
                    },
                    {
                        "id": "01",
                        "description": "General public services",
                        "scheme": "COFOG"
                    }
                ],
                "url": "http://www.glasgow.gov.uk"
            }
        },
        {
            "id": "org-22",
            "name": "Glasgow City Council",
            "identifier": {
                "legalName": "Glasgow City Council"
            },
            "address": {
                "streetAddress": "Chief Executives Department, City Chambers",
                "locality": "Glasgow",
                "region": "UKM82",
                "postalCode": "G2 1DU"
            },
            "contactPoint": {
                "email": "jay.mansfield@glasgow.gov.uk",
                "telephone": "+44 1412872000",
                "faxNumber": "+44 1412879399",
                "url": "http://"
            },
            "roles": [
                "buyer",
                "centralPurchasingBody",
                "reviewBody"
            ],
            "details": {
                "classifications": [
                    {
                        "id": "Regional or local authority",
                        "scheme": "TED_CA_TYPE"
                    },
                    {
                        "id": "01",
                        "description": "General public services",
                        "scheme": "COFOG"
                    }
                ],
                "url": "https://www.glasgow.gov.uk/"
            }
        }
    ],
    "buyer": {
        "name": "Glasgow City Council",
        "id": "org-22"
    },
    "tender": {
        "id": "GCC004305CPU",
        "title": "Burrell Renaissance Construction Project",
        "description": "The appointment of a main contractor to deliver the refurbishment works of the Burrell Renaissance. The Main Building Contract works for the Burrell Renaissance will focus upon renewal/refurbishment of the building envelop, renewal of the building services, creation of an additional entrance and adjacent public events plaza with associated landscaping. Creation of a new central hub within the location of the former auditorium, provision of a new cafe and shop, new community/learning facilities and an accessible collection store. The project scope will include an option for the Contractor to provide hard Facilities Management services for up to 3 years beyond completion of the building works.",
        "status": "complete",
        "items": [
            {
                "id": "1",
                "additionalClassifications": [
                    {
                        "id": "45453100",
                        "scheme": "CPV"
                    }
                ],
                "deliveryLocation": {
                    "description": "UK, Glasgow"
                },
                "deliveryAddresses": [
                    {
                        "region": "UKM34"
                    },
                    {
                        "region": "UKM82"
                    }
                ],
                "relatedLot": "1"
            }
        ],
        "value": {
            "amount": 31600000,
            "currency": "GBP"
        },
        "procurementMethod": "selective",
        "procurementMethodDetails": "Restricted procedure",
        "mainProcurementCategory": "works",
        "submissionMethod": [
            "electronicSubmission"
        ],
        "submissionMethodDetails": "http://www.publictendersscotland.gov.uk",
        "tenderPeriod": {
            "endDate": "2017-06-29T12:00:00Z"
        },
        "documents": [
            {
                "id": "MAY284205",
                "documentType": "contractNotice",
                "title": "Burrell Renaissance Construction Project",
                "description": "The appointment of a main contractor to deliver the refurbishment works of the Burrell Renaissance. The Main Building Contract works for the Burrell Renaissance will focus upon renewal/refurbishment of the building envelop, renewal of the building services, creation of an additional entrance and adjacent public events plaza with associated landscaping. Creation of a new central hub within the location of the former auditorium, provision of a new cafe and shop, new community/learning facilities and an accessible collection store. The project scope will include an option for the Contractor to provide hard Facilities Management services for up to 3 years beyond completion of the building works.",
                "url": "https://www.publiccontractsscotland.gov.uk/search/show/search_view.aspx?ID=MAY284205",
                "format": "text/html"
            },
            {
                "id": "FEB309723",
                "documentType": "awardNotice",
                "title": "Burrell Renaissance Construction Project",
                "description": "The appointment of a main contractor to deliver the refurbishment works of the Burrell Renaissance. The Main Building Contract works for the Burrell Renaissance will focus upon renewal/refurbishment of the building envelop, renewal of the building services, creation of an additional entrance and adjacent public events plaza with associated landscaping. Creation of a new central hub within the location of the former auditorium, provision of a new cafe and shop, new community/learning facilities and an accessible collection store. The project scope will include an option for the Contractor to provide hard Facilities Management services for up to 3 years beyond completion of the building works.",
                "url": "https://www.publiccontractsscotland.gov.uk/search/show/search_view.aspx?ID=FEB309723",
                "format": "text/html"
            }
        ],
        "lots": [
            {
                "id": "1",
                "description": "The appointment of a main contractor to deliver the refurbishment works of the Burrell Renaissance. The Main Building Contract works for the Burrell Renaissance will focus upon renewal/refurbishment of the building envelop, renewal of the building services, creation of an additional entrance and adjacent public events plaza with associated landscaping. Creation of a new central hub within the location of the former auditorium, provision of a new cafe and shop, new community/learning facilities and an accessible collection store. The project scope will include an option for the Contractor to provide hard Facilities Management services for up to 3 years beyond completion of the building works. Further detail on the scope of works is included in the Invitation to Participate document which is available in the buyers attachments area on PCS-T.. Economic operators may be excluded from this competition if there are any of the situations referred to in regulation 58 of the Public Contracts (Scotland) Regulations 2015",
                "status": "complete",
                "hasOptions": false,
                "secondStage": {
                    "minimumCandidates": 5
                },
                "selectionCriteria": {
                    "description": "It is anticipated that the 5 highest scoring bidders will be invited to tender, where 5 bidders can be identified as having meet the minimum criteria for consideration. Where there is a score differential of less than 2% between the fifth placed bidder and subsequent lower ranking bidders, those lower ranking bidders will also be shortlisted and invited to tender, up to a maximum of 7 bidders in total. Only if there is a tie at 7 bidders will more than 7 bidders be invited to tender as all the tied bidders will be invited to tender."
                },
                "submissionTerms": {
                    "variantPolicy": "notAllowed"
                },
                "contractPeriod": {
                    "durationInDays": 720
                },
                "hasRenewal": false
            }
        ],
        "contractTerms": {
            "hasElectronicPayment": true,
            "electronicInvoicingPolicy": "allowed",
            "performanceTerms": "Terms and conditions relating to this contract will be NEC3 Option A with additional Z clauses. Full details of the terms and conditions will be identified at ITT (Invitation to Tender) stage. Key Performance Indicators applicable to the contract will be provided in the Invitation to Tender documentation."
        },
        "coveredBy": [
            "GPA"
        ],
        "secondStage": {
            "invitationDate": "2017-08-17T00:00:00Z"
        },
        "selectionCriteria": {
            "criteria": [
                {
                    "type": "suitability",
                    "description": "Please see ESPD statement documentation found in the buyers attachment area on PCS-T."
                },
                {
                    "type": "economic",
                    "description": "Bidders must comply with the Economic and Financial requirements set out in the document titled Burrell Collection Invitation to Participate which is contained in the buyers attachment area on PCS-T.",
                    "minimum": "Bidders must comply with the Economic and Financial requirements set out in the document titled Burrell Collection Invitation to Participate which is contained in the buyers attachment area on PCS-T."
                },
                {
                    "type": "technical",
                    "description": "Please see the ESPD statement & Invitation to Participate documents found within the buyers attachment area on PCS-T.",
                    "minimum": "Please see the ESPD statement & Invitation to Participate documents found within the buyers attachment area on PCS-T."
                }
            ]
        },
        "submissionTerms": {
            "languages": [
                "en"
            ]
        },
        "classification": {
            "id": "45453100",
            "scheme": "CPV"
        },
        "reviewDetails": "Glasgow City Council (\"the council\") must, by notice in writing a soon as possible after the decision has been made, inform all tenderers and candidates concerned of its decision to award the contract, conclude the framework agreement or establish a dynamic purchasing system. The Council must allow a period of at least the relevant standstill period (where the notice is sent by facsimile or electronic means the period is 10 days ending at midnight at the end of the 10th day after that on which the last notice is sent, when sent by other means he period is 15 days) to elapse between the date of despatch of the notice referred to in Regulation 85(1) of the Public Contracts (Scotland) Regulations 2015 (\"The Regulations\"). The Council is obliged to comply with the regulations and any eligible economic operator can bring an action in the Sherriff Court or the Court of Session where as a consequence of a breach by the Council, suffers or risks suffering loss or damage. The bringing of court proceedings during the standstill period means that the council must not enter into the contract, conclude the framework agreement or establish the dynamic purchasing system unless the proceedings are determined, discontinued or disposed of: or the court, by interim order, brings to an end the prohibition. The bringing of court proceedings after the standstill period has elapsed and the remedies that are available to the courts are detailed in the Regulations. Economic operators can write to the Council seeking further clarification on the notice, to which the Council must respond within 15 days. Economic Operators should be mindful to seek their own independent legal advice when they consider appropriate to do so.",
        "hasRecurrence": false
    },
    "language": "EN",
    "description": "Additional information pertaining to this contract notice is contained in the Invitation to Participate and ESPD statement documents situated within the buyers attachments area of PCS-T. Bidders must ensure they read these documents in line with this contract notice. (SC Ref:527150)",
    "links": [
        {
            "rel": "canonical",
            "href": "https://api.publiccontractsscotland.gov.uk/v1/Notice?id=ocds-r6ebe6-0000491544"
        },
        {
            "rel": "canonical",
            "href": "https://api.publiccontractsscotland.gov.uk/v1/Notice?id=ocds-r6ebe6-0000491544"
        }
    ],
    "noticetype": "OJEU - F3 - Contract Award Notice",
    "awards": [
        {
            "id": "GCC004305CPU",
            "relatedLots": [
                "1"
            ]
        }
    ],
    "contracts": [
        {
            "id": "GCC004305CPU",
            "awardID": "GCC004305CPU",
            "status": "active",
            "dateSigned": "2018-02-08T00:00:00Z"
        }
    ],
    "relatedProcesses": [
        {
            "id": "1",
            "relationship": [
                "planning"
            ],
            "scheme": "EU-OJ",
            "identifier": "2017/S 101-200164"
        }
    ]
}