Notice Information
Notice Title
Modular Buildings and Modern Methods of Construction
Notice Description
YPO are looking for Suppliers to be appointed onto a Framework Agreement following a Competitive Tendering Procedure for the purchase or hire of modular buildings and modern methods of construction. This Framework is designed to meet the needs of YPO customers throughout the United Kingdom.
Lot Information
Purchase of Education Buildings
Provision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions for the education sector, to include but not limited to classrooms, data storage areas, gymnasiums, nurseries, offices, special needs classrooms, staffrooms and technology rooms.
Options: The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded.
Hire of Education BuildingsProvision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, off-hire, relocation, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions for the education sector, to include but not limited to classrooms, data storage areas, gymnasiums, nurseries, offices, special needs classrooms, staffrooms and technology rooms.
Options: The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded.
Purchase of Healthcare BuildingsProvision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions for the healthcare sector, to include but not limited to assessment units, data storage areas, dental surgeries, GP surgeries, offices, operating theatres, pharmacies, staffrooms, waiting areas and wards.
Options: The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded.
Hire of Healthcare BuildingsProvision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, off-hire, relocation, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value(PMV) of 55% including full turnkey solutions for the healthcare sector, to include but not limited to assessment units, data storage areas, dental surgeries, GP surgeries, offices, operating theatres, pharmacies, staffrooms, waiting areas and wards.
Options: The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded.
Purchase of Kitchen BuildingsProvision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions, to include but not limited to dishwashing areas, food preparation and storage areas and production kitchens.
Options: The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded.
Hire of Kitchen BuildingsProvision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, off-hire, relocation, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions, to include but not limited to dish-washing areas, food preparation and storage areas and production kitchens.
Options: The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded.
Purchase of Food Cubes, Kiosks and Modular Catering SystemsProvision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions, to include but not limited to food cubes, servery kiosks, and modular catering systems.
Options: The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded.
Purchase of Restaurant and Cafe BuildingsProvision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions, to include but not limited to cafe, restaurant and welfare facilities.
Options: The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded.
Purchase of Custody Suite BuildingsProvision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions, to include but not limited to cells, charging offices, general custodial space, holding areas, interview rooms, medical and intox rooms, offices, secure storage, server rooms, WC and all other associated requirements.
Options: The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded.
Hire of Custody Suite BuildingsProvision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, off-hire, relocation, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions, to include but not limited to cells, charging offices, general custodial space, holding areas, interview rooms, medical and intox rooms, offices, secure storage, server rooms, WC and all other associated requirements.
Options: The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded.
Purchase of HousingProvision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions, suitable for various occupancy levels. Includes purchase of emergency/temporary shelters and modular pods.
Options: The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded.
Hire of HousingProvision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, off-hire, relocation, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions for temporary housing, to include but not limited to single person and family accommodation and emergency/temporary shelters and modular pods.
Options: The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded.
Purchase of Changing Places BuildingsProvision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, removal and/or maintenance of 2D and 3D primary structural systems including full turnkey solutions, for accessible and inclusive Changing Places facilities. The Changing Places facilities must include: * A height adjustable changing bench * A tracking hoist system * Adequate space (at least 12 square metres wherever possible) * A centrally placed toilet with room either side for the carers and drop-down handrails * A screen or curtain * Wide tear off paper roll to cover the bench * A large waste bin for disposable pads * A non-slip floor All buildings must be compliant with Changing Places Consortium minimum requirements to enable registration with them.
Options: The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded.
Purchase of Bespoke BuildingsProvision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions, to include any requirements not covered by the other Lots and mixed construction methods. This includes but is not limited to data centres, retail or storage units, multi-use community spaces, workshops, crisis response units, cultural and leisure spaces, laboratories, crematoria and mortuary units.
Options: The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded.
Hire of Bespoke BuildingsProvision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, off-hire, relocation, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions, to include any requirements not covered by the other lots and mixed construction methods. This includes but is not limited to data centres, retail or storage units, multi-use community spaces, workshops, crisis response units, cultural and leisure spaces, staging, laboratories, crematoria and mortuary units.
Options: The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded.
Planning Information
A PIN was published 22/08/2025. With the following information: In order to gain further insight into the modular building market YPO intends to issue a questionnaire, with the responses helping to determine the most effective structure for the proposed framework. Further engagement activity may be conducted with respondents to clarify responses. All respondents to the PIN were issued with a questionnaire.
Notice Details
Publication & Lifecycle
- Open Contracting ID
- ocds-h6vhtk-04e8df
- Publication Source
- Find A Tender Service
- Latest Notice
- https://www.find-tender.service.gov.uk/Notice/063847-2025
- Current Stage
- Tender
- All Stages
- Planning, Tender
Procurement Classification
- Notice Type
- UK4 - Tender Notice
- Procurement Type
- Framework
- Procurement Category
- Goods
- Procurement Method
- Open
- Procurement Method Details
- Open procedure
- Tender Suitability
- SME, VCSE
- Awardee Scale
- Not specified
Common Procurement Vocabulary (CPV)
- CPV Divisions
44 - Construction structures and materials; auxiliary products to construction (except electric apparatus)
45 - Construction work
70 - Real estate services
71 - Architectural, construction, engineering and inspection services
-
- CPV Codes
44211000 - Prefabricated buildings
45000000 - Construction work
70310000 - Building rental or sale services
71000000 - Architectural, construction, engineering and inspection services
Notice Value(s)
- Tender Value
- £400,000,000 £100M-£1B
- Lots Value
- £400,000,000 £100M-£1B
- Awards Value
- Not specified
- Contracts Value
- Not specified
Notice Dates
- Publication Date
- 9 Oct 20251 months ago
- Submission Deadline
- 7 Nov 2025Expired
- Future Notice Date
- 17 Mar 2025Expired
- Award Date
- Not specified
- Contract Period
- 18 Dec 2025 - 17 Dec 2029 4-5 years
- Recurrence
- Not specified
Notice Status
- Tender Status
- Active
- Lots Status
- Active
- Awards Status
- Not Specified
- Contracts Status
- Not Specified
Buyer & Supplier
Contracting Authority (Buyer)
- Main Buyer
- YORKSHIRE PURCHASING ORGANISATION
- Contact Name
- Kath Johnson
- Contact Email
- contracts@ypo.co.uk
- Contact Phone
- +447966886167
Buyer Location
- Locality
- WAKEFIELD
- Postcode
- WF2 0XE
- Post Town
- Wakefield
- Country
- England
-
- Major Region (ITL 1)
- TLE Yorkshire and The Humber
- Basic Region (ITL 2)
- TLE4 West Yorkshire
- Small Region (ITL 3)
- TLE45 Wakefield
- Delivery Location
- Not specified
-
- Local Authority
- Wakefield
- Electoral Ward
- Wrenthorpe and Outwood West
- Westminster Constituency
- Wakefield and Rothwell
Further Information
Notice Documents
-
https://www.find-tender.service.gov.uk/Notice/063847-2025
9th October 2025 - Tender notice on Find a Tender -
https://www.find-tender.service.gov.uk/Notice/057788-2025
18th September 2025 - Tender notice on Find a Tender -
https://www.find-tender.service.gov.uk/Notice/007618-2025
3rd March 2025 - Preliminary market engagement notice on Find a Tender
Open Contracting Data Standard (OCDS)
View full OCDS Record for this contracting process
The Open Contracting Data Standard (OCDS) is a framework designed to increase transparency and access to public procurement data in the public sector. It is widely used by governments and organisations worldwide to report on procurement processes and contracts.
{
"tag": [
"compiled"
],
"id": "ocds-h6vhtk-04e8df-2025-10-09T15:55:32+01:00",
"date": "2025-10-09T15:55:32+01:00",
"ocid": "ocds-h6vhtk-04e8df",
"initiationType": "tender",
"parties": [
{
"id": "GB-PPON-PMRV-4748-MNJV",
"name": "Yorkshire Purchasing Organisation",
"identifier": {
"scheme": "GB-PPON",
"id": "PMRV-4748-MNJV"
},
"address": {
"streetAddress": "41 Industrial Park",
"locality": "Wakefield",
"postalCode": "WF2 0XE",
"country": "GB",
"countryName": "United Kingdom",
"region": "UKE45"
},
"contactPoint": {
"name": "Kath Johnson",
"email": "contracts@ypo.co.uk",
"telephone": "+447966886167"
},
"roles": [
"buyer"
],
"details": {
"url": "http://www.ypo.co.uk",
"classifications": [
{
"scheme": "UK_CA_TYPE",
"id": "publicAuthoritySubCentralGovernment",
"description": "Public authority - sub-central government"
}
]
}
}
],
"buyer": {
"id": "GB-PPON-PMRV-4748-MNJV",
"name": "Yorkshire Purchasing Organisation"
},
"planning": {
"milestones": [
{
"id": "engagement",
"type": "engagement",
"description": "A PIN was published 22/08/2025. With the following information: In order to gain further insight into the modular building market YPO intends to issue a questionnaire, with the responses helping to determine the most effective structure for the proposed framework. Further engagement activity may be conducted with respondents to clarify responses. All respondents to the PIN were issued with a questionnaire.",
"dateMet": "2025-02-21T00:00:00Z",
"status": "met"
}
],
"documents": [
{
"id": "007618-2025",
"documentType": "marketEngagementNotice",
"noticeType": "UK2",
"description": "Preliminary market engagement notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/007618-2025",
"datePublished": "2025-03-03T10:18:57Z",
"format": "text/html"
}
]
},
"tender": {
"id": "001230",
"legalBasis": {
"id": "2023/54",
"scheme": "UKPGA",
"uri": "https://www.legislation.gov.uk/ukpga/2023/54/contents"
},
"title": "Modular Buildings and Modern Methods of Construction",
"description": "YPO are looking for Suppliers to be appointed onto a Framework Agreement following a Competitive Tendering Procedure for the purchase or hire of modular buildings and modern methods of construction. This Framework is designed to meet the needs of YPO customers throughout the United Kingdom.",
"items": [
{
"id": "1",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "44211000",
"description": "Prefabricated buildings"
},
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
},
{
"scheme": "CPV",
"id": "70310000",
"description": "Building rental or sale services"
},
{
"scheme": "CPV",
"id": "71000000",
"description": "Architectural, construction, engineering and inspection services"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
}
],
"relatedLot": "1"
},
{
"id": "2",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "44211000",
"description": "Prefabricated buildings"
},
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
},
{
"scheme": "CPV",
"id": "70310000",
"description": "Building rental or sale services"
},
{
"scheme": "CPV",
"id": "71000000",
"description": "Architectural, construction, engineering and inspection services"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
}
],
"relatedLot": "2"
},
{
"id": "3",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "44211000",
"description": "Prefabricated buildings"
},
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
},
{
"scheme": "CPV",
"id": "70310000",
"description": "Building rental or sale services"
},
{
"scheme": "CPV",
"id": "71000000",
"description": "Architectural, construction, engineering and inspection services"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
}
],
"relatedLot": "3"
},
{
"id": "4",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "44211000",
"description": "Prefabricated buildings"
},
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
},
{
"scheme": "CPV",
"id": "70310000",
"description": "Building rental or sale services"
},
{
"scheme": "CPV",
"id": "71000000",
"description": "Architectural, construction, engineering and inspection services"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
}
],
"relatedLot": "4"
},
{
"id": "5",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "44211000",
"description": "Prefabricated buildings"
},
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
},
{
"scheme": "CPV",
"id": "70310000",
"description": "Building rental or sale services"
},
{
"scheme": "CPV",
"id": "71000000",
"description": "Architectural, construction, engineering and inspection services"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
}
],
"relatedLot": "5"
},
{
"id": "6",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "44211000",
"description": "Prefabricated buildings"
},
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
},
{
"scheme": "CPV",
"id": "70310000",
"description": "Building rental or sale services"
},
{
"scheme": "CPV",
"id": "71000000",
"description": "Architectural, construction, engineering and inspection services"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
}
],
"relatedLot": "6"
},
{
"id": "7",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "44211000",
"description": "Prefabricated buildings"
},
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
},
{
"scheme": "CPV",
"id": "70310000",
"description": "Building rental or sale services"
},
{
"scheme": "CPV",
"id": "71000000",
"description": "Architectural, construction, engineering and inspection services"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
}
],
"relatedLot": "7"
},
{
"id": "8",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "44211000",
"description": "Prefabricated buildings"
},
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
},
{
"scheme": "CPV",
"id": "70310000",
"description": "Building rental or sale services"
},
{
"scheme": "CPV",
"id": "71000000",
"description": "Architectural, construction, engineering and inspection services"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
}
],
"relatedLot": "8"
},
{
"id": "9",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "44211000",
"description": "Prefabricated buildings"
},
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
},
{
"scheme": "CPV",
"id": "70310000",
"description": "Building rental or sale services"
},
{
"scheme": "CPV",
"id": "71000000",
"description": "Architectural, construction, engineering and inspection services"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
}
],
"relatedLot": "9"
},
{
"id": "10",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "44211000",
"description": "Prefabricated buildings"
},
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
},
{
"scheme": "CPV",
"id": "70310000",
"description": "Building rental or sale services"
},
{
"scheme": "CPV",
"id": "71000000",
"description": "Architectural, construction, engineering and inspection services"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
}
],
"relatedLot": "10"
},
{
"id": "11",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "44211000",
"description": "Prefabricated buildings"
},
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
},
{
"scheme": "CPV",
"id": "70310000",
"description": "Building rental or sale services"
},
{
"scheme": "CPV",
"id": "71000000",
"description": "Architectural, construction, engineering and inspection services"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
}
],
"relatedLot": "11"
},
{
"id": "12",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "44211000",
"description": "Prefabricated buildings"
},
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
},
{
"scheme": "CPV",
"id": "70310000",
"description": "Building rental or sale services"
},
{
"scheme": "CPV",
"id": "71000000",
"description": "Architectural, construction, engineering and inspection services"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
}
],
"relatedLot": "12"
},
{
"id": "13",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "44211000",
"description": "Prefabricated buildings"
},
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
},
{
"scheme": "CPV",
"id": "70310000",
"description": "Building rental or sale services"
},
{
"scheme": "CPV",
"id": "71000000",
"description": "Architectural, construction, engineering and inspection services"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
}
],
"relatedLot": "13"
},
{
"id": "14",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "44211000",
"description": "Prefabricated buildings"
},
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
},
{
"scheme": "CPV",
"id": "70310000",
"description": "Building rental or sale services"
},
{
"scheme": "CPV",
"id": "71000000",
"description": "Architectural, construction, engineering and inspection services"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
}
],
"relatedLot": "14"
},
{
"id": "15",
"additionalClassifications": [
{
"scheme": "CPV",
"id": "44211000",
"description": "Prefabricated buildings"
},
{
"scheme": "CPV",
"id": "45000000",
"description": "Construction work"
},
{
"scheme": "CPV",
"id": "70310000",
"description": "Building rental or sale services"
},
{
"scheme": "CPV",
"id": "71000000",
"description": "Architectural, construction, engineering and inspection services"
}
],
"deliveryAddresses": [
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
},
{
"region": "UK",
"country": "GB",
"countryName": "United Kingdom"
},
{
"region": "GG",
"country": "GG",
"countryName": "Guernsey"
},
{
"region": "IM",
"country": "IM",
"countryName": "Isle of Man"
},
{
"region": "JE",
"country": "JE",
"countryName": "Jersey"
}
],
"relatedLot": "15"
}
],
"mainProcurementCategory": "goods",
"techniques": {
"hasFrameworkAgreement": true,
"frameworkAgreement": {
"method": "withAndWithoutReopeningCompetition",
"type": "open",
"buyerCategories": "Any permissible user: https://www.ypo.co.uk/about/governance/transparency/permissible-users",
"description": "For the purposes of this Framework Agreement YPO has classified the Call-off route as an Award Without Competition or Competitive Selection Process. The mechanism for Supplier selection for an Award Without Competition will be as follows: - Mechanism for Lots with only one supplier will be based on awarding without competition to the sole provider within that Lot. - Mechanism for Lots with multiple suppliers will be based on the objective mechanism for award The Supplier will be ranked based on the evaluation of this Tender exercise. An Award Without Competition can be made to a highest ranked Supplier who can meet the Contracting Authority's specific requirements, which reflect the most advantageous offer. The Contracting Authority's specific requirements will include the following: * Ability to meet customer requirements * Ability to deliver to Contracting Authority's required location * Ability to deliver to Contracting Authority's required lead time * For hire Lots, the ability to hire for the Contracting Authority's required hire period. The Supplier or the Customer may request a site visit prior to the order being placed, strictly for the purposes of confirming suitability of the site for the intended project e.g. confirmation that standard vehicular access is feasible. In the event of more than one Supplier achieving the same overall Award Criteria score, ranking will be determined by the highest score in the Cost Criteria. If Cost Criteria scores are equal, Quality Criteria scores will be considered next, followed by Delivery Criteria scores if necessary. For an Award Without Competition, a mechanism for determining price payable will be as follows: - Tenders Response to the Pricing Schedule For Competitive Selection Process, the mechanism for determining price payable will be described in the Contracting Authority's call-off documentation."
}
},
"lots": [
{
"id": "1",
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2025-12-18T00:00:00Z",
"endDate": "2029-12-17T23:59:59Z"
},
"status": "active",
"title": "Purchase of Education Buildings",
"description": "Provision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions for the education sector, to include but not limited to classrooms, data storage areas, gymnasiums, nurseries, offices, special needs classrooms, staffrooms and technology rooms.",
"value": {
"amountGross": 500000000,
"amount": 400000000,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "cost",
"name": "Cost",
"numbers": [
{
"number": 40,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Quality",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Delivery and Customer Service",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Social Value",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
}
]
},
"hasOptions": true,
"options": {
"description": "The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded."
}
},
{
"id": "2",
"title": "Hire of Education Buildings",
"description": "Provision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, off-hire, relocation, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions for the education sector, to include but not limited to classrooms, data storage areas, gymnasiums, nurseries, offices, special needs classrooms, staffrooms and technology rooms.",
"status": "active",
"value": {
"amountGross": 500000000,
"amount": 400000000,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "cost",
"name": "Cost",
"numbers": [
{
"number": 40,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Quality",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Delivery and Customer Service",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Social Value",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2025-12-18T00:00:00Z",
"endDate": "2029-12-17T23:59:59Z"
},
"hasOptions": true,
"options": {
"description": "The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded."
}
},
{
"id": "3",
"title": "Purchase of Healthcare Buildings",
"description": "Provision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions for the healthcare sector, to include but not limited to assessment units, data storage areas, dental surgeries, GP surgeries, offices, operating theatres, pharmacies, staffrooms, waiting areas and wards.",
"status": "active",
"value": {
"amountGross": 500000000,
"amount": 400000000,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "cost",
"name": "Cost",
"numbers": [
{
"number": 40,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Quality",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Delivery and Customer Service",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Social Value",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2025-12-18T00:00:00Z",
"endDate": "2029-12-17T23:59:59Z"
},
"hasOptions": true,
"options": {
"description": "The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded."
}
},
{
"id": "4",
"title": "Hire of Healthcare Buildings",
"description": "Provision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, off-hire, relocation, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value(PMV) of 55% including full turnkey solutions for the healthcare sector, to include but not limited to assessment units, data storage areas, dental surgeries, GP surgeries, offices, operating theatres, pharmacies, staffrooms, waiting areas and wards.",
"status": "active",
"value": {
"amountGross": 500000000,
"amount": 400000000,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "cost",
"name": "Cost",
"numbers": [
{
"number": 40,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Quality",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Delivery and Customer Service",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Social Value",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2025-12-18T00:00:00Z",
"endDate": "2029-12-17T23:59:59Z"
},
"hasOptions": true,
"options": {
"description": "The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded."
}
},
{
"id": "5",
"title": "Purchase of Kitchen Buildings",
"description": "Provision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions, to include but not limited to dishwashing areas, food preparation and storage areas and production kitchens.",
"status": "active",
"value": {
"amountGross": 500000000,
"amount": 400000000,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "cost",
"name": "Cost",
"numbers": [
{
"number": 40,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Quality",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Delivery and Customer Service",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Social Value",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2025-12-18T00:00:00Z",
"endDate": "2029-12-17T23:59:59Z"
},
"hasOptions": true,
"options": {
"description": "The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded."
}
},
{
"id": "6",
"title": "Hire of Kitchen Buildings",
"description": "Provision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, off-hire, relocation, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions, to include but not limited to dish-washing areas, food preparation and storage areas and production kitchens.",
"status": "active",
"value": {
"amountGross": 500000000,
"amount": 400000000,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "cost",
"name": "Cost",
"numbers": [
{
"number": 40,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Quality",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Delivery and Customer Service",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Social Value",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2025-12-18T00:00:00Z",
"endDate": "2029-12-17T23:59:59Z"
},
"hasOptions": true,
"options": {
"description": "The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded."
}
},
{
"id": "7",
"title": "Purchase of Food Cubes, Kiosks and Modular Catering Systems",
"description": "Provision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions, to include but not limited to food cubes, servery kiosks, and modular catering systems.",
"status": "active",
"value": {
"amountGross": 500000000,
"amount": 400000000,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "cost",
"name": "Cost",
"numbers": [
{
"number": 40,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Quality",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Delivery and Customer Service",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Social Value",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2025-12-18T00:00:00Z",
"endDate": "2029-12-17T23:59:59Z"
},
"hasOptions": true,
"options": {
"description": "The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded."
}
},
{
"id": "8",
"title": "Purchase of Restaurant and Cafe Buildings",
"description": "Provision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions, to include but not limited to cafe, restaurant and welfare facilities.",
"status": "active",
"value": {
"amountGross": 500000000,
"amount": 400000000,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "cost",
"name": "Cost",
"numbers": [
{
"number": 40,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Quality",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Delivery and Customer Service",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Social Value",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2025-12-18T00:00:00Z",
"endDate": "2029-12-17T23:59:59Z"
},
"hasOptions": true,
"options": {
"description": "The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded."
}
},
{
"id": "9",
"title": "Purchase of Custody Suite Buildings",
"description": "Provision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions, to include but not limited to cells, charging offices, general custodial space, holding areas, interview rooms, medical and intox rooms, offices, secure storage, server rooms, WC and all other associated requirements.",
"status": "active",
"value": {
"amountGross": 500000000,
"amount": 400000000,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "cost",
"name": "Cost",
"numbers": [
{
"number": 40,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Quality",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Delivery and Customer Service",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Social Value",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2025-12-18T00:00:00Z",
"endDate": "2029-12-17T23:59:59Z"
},
"hasOptions": true,
"options": {
"description": "The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded."
}
},
{
"id": "10",
"title": "Hire of Custody Suite Buildings",
"description": "Provision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, off-hire, relocation, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions, to include but not limited to cells, charging offices, general custodial space, holding areas, interview rooms, medical and intox rooms, offices, secure storage, server rooms, WC and all other associated requirements.",
"status": "active",
"value": {
"amountGross": 500000000,
"amount": 400000000,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "cost",
"name": "Cost",
"numbers": [
{
"number": 40,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Quality",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Delivery and Customer Service",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Social Value",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2025-12-18T00:00:00Z",
"endDate": "2029-12-17T23:59:59Z"
},
"hasOptions": true,
"options": {
"description": "The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded."
}
},
{
"id": "11",
"title": "Purchase of Housing",
"description": "Provision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions, suitable for various occupancy levels. Includes purchase of emergency/temporary shelters and modular pods.",
"status": "active",
"value": {
"amountGross": 500000000,
"amount": 400000000,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "cost",
"name": "Cost",
"numbers": [
{
"number": 40,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Quality",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Delivery and Customer Service",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Social Value",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2025-12-18T00:00:00Z",
"endDate": "2029-12-17T23:59:59Z"
},
"hasOptions": true,
"options": {
"description": "The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded."
}
},
{
"id": "12",
"title": "Hire of Housing",
"description": "Provision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, off-hire, relocation, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions for temporary housing, to include but not limited to single person and family accommodation and emergency/temporary shelters and modular pods.",
"status": "active",
"value": {
"amountGross": 500000000,
"amount": 400000000,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "cost",
"name": "Cost",
"numbers": [
{
"number": 40,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Quality",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Delivery and Customer Service",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Social Value",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2025-12-18T00:00:00Z",
"endDate": "2029-12-17T23:59:59Z"
},
"hasOptions": true,
"options": {
"description": "The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded."
}
},
{
"id": "13",
"title": "Purchase of Changing Places Buildings",
"description": "Provision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, removal and/or maintenance of 2D and 3D primary structural systems including full turnkey solutions, for accessible and inclusive Changing Places facilities. The Changing Places facilities must include: * A height adjustable changing bench * A tracking hoist system * Adequate space (at least 12 square metres wherever possible) * A centrally placed toilet with room either side for the carers and drop-down handrails * A screen or curtain * Wide tear off paper roll to cover the bench * A large waste bin for disposable pads * A non-slip floor All buildings must be compliant with Changing Places Consortium minimum requirements to enable registration with them.",
"status": "active",
"value": {
"amountGross": 500000000,
"amount": 400000000,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "cost",
"name": "Cost",
"numbers": [
{
"number": 40,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Quality",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Delivery and Customer Service",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Social Value",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2025-12-18T00:00:00Z",
"endDate": "2029-12-17T23:59:59Z"
},
"hasOptions": true,
"options": {
"description": "The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded."
}
},
{
"id": "14",
"title": "Purchase of Bespoke Buildings",
"description": "Provision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions, to include any requirements not covered by the other Lots and mixed construction methods. This includes but is not limited to data centres, retail or storage units, multi-use community spaces, workshops, crisis response units, cultural and leisure spaces, laboratories, crematoria and mortuary units.",
"status": "active",
"value": {
"amountGross": 500000000,
"amount": 400000000,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "cost",
"name": "Cost",
"numbers": [
{
"number": 40,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Quality",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Delivery and Customer Service",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Social Value",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2025-12-18T00:00:00Z",
"endDate": "2029-12-17T23:59:59Z"
},
"hasOptions": true,
"options": {
"description": "The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded."
}
},
{
"id": "15",
"title": "Hire of Bespoke Buildings",
"description": "Provision of design, manufacture, supply, project management, installation, commissioning/de-commissioning, restoration, off-hire, relocation, removal and/or maintenance of 2D and 3D primary structural systems with a minimum pre-manufactured value (PMV) of 55% including full turnkey solutions, to include any requirements not covered by the other lots and mixed construction methods. This includes but is not limited to data centres, retail or storage units, multi-use community spaces, workshops, crisis response units, cultural and leisure spaces, staging, laboratories, crematoria and mortuary units.",
"status": "active",
"value": {
"amountGross": 500000000,
"amount": 400000000,
"currency": "GBP"
},
"awardCriteria": {
"criteria": [
{
"type": "cost",
"name": "Cost",
"numbers": [
{
"number": 40,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Quality",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Delivery and Customer Service",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
},
{
"type": "quality",
"name": "Social Value",
"numbers": [
{
"number": 20,
"weight": "percentageExact"
}
]
}
]
},
"suitability": {
"sme": true,
"vcse": true
},
"contractPeriod": {
"startDate": "2025-12-18T00:00:00Z",
"endDate": "2029-12-17T23:59:59Z"
},
"hasOptions": true,
"options": {
"description": "The right to additional purchases while the contract is valid. Any resulting Contract shall be deemed to cover any item that can be supplied by the successful Tenderer(s) over the life of the Contract within the scope of the lot awarded."
}
}
],
"communication": {
"futureNoticeDate": "2025-03-17T23:59:59Z"
},
"status": "active",
"value": {
"amountGross": 500000000,
"amount": 400000000,
"currency": "GBP"
},
"procurementMethod": "open",
"procurementMethodDetails": "Open procedure",
"aboveThreshold": true,
"participationFees": [
{
"id": "ocds-h6vhtk-04e8df",
"type": [
"win"
],
"relativeValue": {
"proportion": 0.01,
"monetaryValue": "award"
}
}
],
"submissionMethodDetails": "https://procontract.due-north.com/register?ReadForm",
"submissionTerms": {
"electronicSubmissionPolicy": "allowed",
"languages": [
"en"
]
},
"tenderPeriod": {
"endDate": "2025-11-07T17:00:00Z"
},
"enquiryPeriod": {
"endDate": "2025-10-17T17:00:00+01:00"
},
"awardPeriod": {
"endDate": "2025-12-12T23:59:59Z"
},
"documents": [
{
"id": "conflictOfInterest",
"documentType": "conflictOfInterest",
"description": "Not published"
},
{
"id": "057788-2025",
"documentType": "tenderNotice",
"noticeType": "UK4",
"description": "Tender notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/057788-2025",
"datePublished": "2025-09-18T15:17:27+01:00",
"format": "text/html"
},
{
"id": "063847-2025",
"documentType": "tenderNotice",
"noticeType": "UK4",
"description": "Tender notice on Find a Tender",
"url": "https://www.find-tender.service.gov.uk/Notice/063847-2025",
"datePublished": "2025-10-09T15:55:32+01:00",
"format": "text/html"
}
],
"riskDetails": "-Supply Chain Disruption for Key Modular Components - There is a known risk of disruption in the supply of prefabricated modular units, specialist materials (e.g. fire-rated panels, acoustic insulation), and mechanical/electrical components due to global market volatility, geopolitical tensions, and shipping delays. While mitigation strategies such as multi-sourcing are planned, the risk cannot be fully eliminated. -Shortage of Skilled Labour for Modular Installation -There is a known risk of limited availability of skilled labour for modular construction and installation, particularly in remote or high-demand regions. This may affect delivery timelines or require changes to subcontracting arrangements. -Changes in Building Regulations or Standards- Updates to building codes, fire safety regulations, or sustainability standards during the framework term may require design or specification changes to modular units. While YPO will monitor regulatory developments, such changes cannot be predicted or accounted for in full at this stage. -Site Access Constraints - Certain sites within the framework may present access challenges due to third-party land ownership, infrastructure works, or unforeseen environmental conditions. These constraints may delay installation or require alternative delivery methods. YPO is unable to confirm site readiness across all locations at this stage.",
"amendments": [
{
"id": "063847-2025",
"description": "There is an extension to the enquiry deadline, submission deadline and award decision date (estimated) in response to enquiries."
}
]
},
"language": "en"
}