Notice Information
Notice Title
Supply, Installation, Commissioning and Maintenance of Electric Vehicle Charging Points at Elderslie Village Hall, Howwood Village Hall, ON-X Sports Centre and Johnstone Sports Hub
Notice Description
The Council seeks a Contractor to supply, install and commission electric vehicle charging points (including carrying out of planned and reactive maintenance) at Elderslie Village Hall, Howwood Village Hall, ON-X Sports Centre and Johnstone Sports Hub.
Lot Information
Lot 1
The project comprises 2 specific phases: Phase 1 - Supply, Install and Commissioning of Electric Charging Points Phase 2 - Planned and reactive maintenance of Electric Charging Points The successful tenderer will be awarded a contract in respect of each phase. Phase 1 will involve the supply and carrying out of all civil works (Groundworks, cabling and reinstatement of footways and carriageways), installation of Electric Vehicle charging points including protective barriers, bay markings, signage and electrical functional testing of electric vehicle charging equipment and shall thereafter also include the commissioning of the chargers at Elderslie Village Hall, Howwood Village Hall, ON-X Sports Centre and Johnstone Sports Hub. The Phase 1 Conditions of Contract will be the NEC3 Engineering & Construction Short Contract April 2013 with Z Clauses. Phase 2 will involve maintenance of Electric Vehicle charging points at Elderslie Village Hall, Howwood Village Hall, ON-X Sports Centre and Johnstone Sports Hub. by providing annual preventative maintenance including mechanical and electrical safety checks, active monitoring of EV charging points and replacement of damaged EV charger equipment (excluding any damage that could not be attributed to normal use), as well as any reactive maintenance. The Phase 2 Conditions of Contract will be in the form of NEC3 Term Service Short Contract April 2013 with Z Clauses. Tenderers should note that Phase 2 is a Term Service Contract with no guarantee of spend under Part 2 Services. Phase 2 contract shall commence when practical completion has been achieved under the Phase 1 contract (anticipated to be 2 months from the contracts start date) and run for a period of 5 years.
Notice Details
Publication & Lifecycle
- Open Contracting ID
- ocds-r6ebe6-0000650700
- Publication Source
- Public Contracts Scotland
- Latest Notice
- https://www.publiccontractsscotland.gov.uk/search/show/search_view.aspx?ID=APR412013
- Current Stage
- Award
- All Stages
- Award
Procurement Classification
- Notice Type
- PCS Notice - Website Contract Award Notice
- Procurement Type
- Standard
- Procurement Category
- Works
- Procurement Method
- Open
- Procurement Method Details
- Open procedure
- Tender Suitability
- Not specified
- Awardee Scale
- SME
Common Procurement Vocabulary (CPV)
- CPV Divisions
31 - Electrical machinery, apparatus, equipment and consumables; lighting
34 - Transport equipment and auxiliary products to transportation
45 - Construction work
-
- CPV Codes
31158000 - Chargers
34144900 - Electric vehicles
45317000 - Other electrical installation work
Notice Value(s)
- Tender Value
- Not specified
- Lots Value
- Not specified
- Awards Value
- Not specified
- Contracts Value
- £65,870 Under £100K
Notice Dates
- Publication Date
- 13 Apr 20214 years ago
- Submission Deadline
- Not specified
- Future Notice Date
- Not specified
- Award Date
- 31 Mar 20214 years ago
- Contract Period
- Not specified - Not specified
- Recurrence
- Not specified
Notice Status
- Tender Status
- Complete
- Lots Status
- Complete
- Awards Status
- Not Specified
- Contracts Status
- Active
Buyer & Supplier
Contracting Authority (Buyer)
- Main Buyer
- RENFREWSHIRE COUNCIL
- Contact Name
- Not specified
- Contact Email
- cpu@renfrewshire.gov.uk
- Contact Phone
- +44 3003000300
Buyer Location
- Locality
- PAISLEY
- Postcode
- PA1 1JB
- Post Town
- Paisley
- Country
- Scotland
-
- Major Region (ITL 1)
- TLM Scotland
- Basic Region (ITL 2)
- TLM3 West Central Scotland
- Small Region (ITL 3)
- TLM33 Inverclyde, East Renfrewshire, and Renfrewshire
- Delivery Location
- TLM83 Inverclyde, East Renfrewshire, and Renfrewshire
-
- Local Authority
- Renfrewshire
- Electoral Ward
- Paisley East and Central
- Westminster Constituency
- Paisley and Renfrewshire South
Further Information
Notice Documents
-
https://www.publiccontractsscotland.gov.uk/search/show/search_view.aspx?ID=APR412013
Supply, Installation, Commissioning and Maintenance of Electric Vehicle Charging Points at Elderslie Village Hall, Howwood Village Hall, ON-X Sports Centre and Johnstone Sports Hub - The Council seeks a Contractor to supply, install and commission electric vehicle charging points (including carrying out of planned and reactive maintenance) at Elderslie Village Hall, Howwood Village Hall, ON-X Sports Centre and Johnstone Sports Hub.
Open Contracting Data Standard (OCDS)
View full OCDS Record for this contracting process
The Open Contracting Data Standard (OCDS) is a framework designed to increase transparency and access to public procurement data in the public sector. It is widely used by governments and organisations worldwide to report on procurement processes and contracts.
{
"tag": [
"compiled"
],
"id": "ocds-r6ebe6-0000650700-2021-04-13T00:00:00Z",
"date": "2021-04-13T00:00:00Z",
"ocid": "ocds-r6ebe6-0000650700",
"initiationType": "tender",
"parties": [
{
"id": "org-118",
"name": "Renfrewshire Council",
"identifier": {
"legalName": "Renfrewshire Council"
},
"address": {
"streetAddress": "Renfrewshire House, Cotton Street",
"locality": "Paisley",
"region": "UKM83",
"postalCode": "PA1 1JB"
},
"contactPoint": {
"email": "cpu@renfrewshire.gov.uk",
"telephone": "+44 3003000300",
"url": "http://"
},
"roles": [
"buyer",
"centralPurchasingBody"
],
"details": {
"classifications": [
{
"id": "Regional or local authority",
"scheme": "TED_CA_TYPE"
},
{
"id": "01",
"description": "General public services",
"scheme": "COFOG"
}
],
"url": "http://www.renfrewshire.gov.uk"
}
},
{
"id": "org-333",
"name": "SWARCO UK LTD",
"identifier": {
"legalName": "SWARCO UK LTD"
},
"address": {
"streetAddress": "Unit 1, Maxted Corner, Maxted Road",
"locality": "Hemel Hempstead",
"region": "UKM",
"postalCode": "HP2 7RA"
},
"contactPoint": {
"telephone": "+44 07971878146"
},
"roles": [
"supplier"
],
"details": {
"scale": "sme",
"url": "http://"
}
},
{
"id": "org-334",
"name": "See VI.4.3 Below",
"identifier": {
"legalName": "See VI.4.3 Below"
},
"address": {
"locality": "UK"
},
"contactPoint": {
"url": "http://"
},
"roles": [
"reviewBody"
]
},
{
"id": "org-120",
"name": "Please refer to VI.4.3 below",
"identifier": {
"legalName": "Please refer to VI.4.3 below"
},
"address": {
"streetAddress": "UK",
"locality": "UK"
},
"contactPoint": {
"url": "http://"
},
"roles": [
"reviewBody",
"mediationBody"
]
},
{
"id": "org-121",
"name": "Court of Session",
"identifier": {
"legalName": "Court of Session"
},
"address": {
"streetAddress": "Parliament Square",
"locality": "Edinburgh",
"postalCode": "EH1 1RQ"
},
"contactPoint": {
"url": "http://"
},
"roles": [
"reviewContactPoint"
]
}
],
"buyer": {
"name": "Renfrewshire Council",
"id": "org-118"
},
"tender": {
"id": "RC-CPU-20-092",
"title": "Supply, Installation, Commissioning and Maintenance of Electric Vehicle Charging Points at Elderslie Village Hall, Howwood Village Hall, ON-X Sports Centre and Johnstone Sports Hub",
"description": "The Council seeks a Contractor to supply, install and commission electric vehicle charging points (including carrying out of planned and reactive maintenance) at Elderslie Village Hall, Howwood Village Hall, ON-X Sports Centre and Johnstone Sports Hub.",
"status": "complete",
"items": [
{
"id": "1",
"additionalClassifications": [
{
"id": "34144900",
"scheme": "CPV"
},
{
"id": "31158000",
"scheme": "CPV"
}
],
"deliveryAddresses": [
{
"region": "UKM83"
}
],
"relatedLot": "1"
}
],
"procurementMethod": "open",
"procurementMethodDetails": "Open procedure",
"mainProcurementCategory": "works",
"documents": [
{
"id": "APR412013",
"documentType": "awardNotice",
"title": "Supply, Installation, Commissioning and Maintenance of Electric Vehicle Charging Points at Elderslie Village Hall, Howwood Village Hall, ON-X Sports Centre and Johnstone Sports Hub",
"description": "The Council seeks a Contractor to supply, install and commission electric vehicle charging points (including carrying out of planned and reactive maintenance) at Elderslie Village Hall, Howwood Village Hall, ON-X Sports Centre and Johnstone Sports Hub.",
"url": "https://www.publiccontractsscotland.gov.uk/search/show/search_view.aspx?ID=APR412013",
"format": "text/html"
}
],
"lots": [
{
"id": "1",
"description": "The project comprises 2 specific phases: Phase 1 - Supply, Install and Commissioning of Electric Charging Points Phase 2 - Planned and reactive maintenance of Electric Charging Points The successful tenderer will be awarded a contract in respect of each phase. Phase 1 will involve the supply and carrying out of all civil works (Groundworks, cabling and reinstatement of footways and carriageways), installation of Electric Vehicle charging points including protective barriers, bay markings, signage and electrical functional testing of electric vehicle charging equipment and shall thereafter also include the commissioning of the chargers at Elderslie Village Hall, Howwood Village Hall, ON-X Sports Centre and Johnstone Sports Hub. The Phase 1 Conditions of Contract will be the NEC3 Engineering & Construction Short Contract April 2013 with Z Clauses. Phase 2 will involve maintenance of Electric Vehicle charging points at Elderslie Village Hall, Howwood Village Hall, ON-X Sports Centre and Johnstone Sports Hub. by providing annual preventative maintenance including mechanical and electrical safety checks, active monitoring of EV charging points and replacement of damaged EV charger equipment (excluding any damage that could not be attributed to normal use), as well as any reactive maintenance. The Phase 2 Conditions of Contract will be in the form of NEC3 Term Service Short Contract April 2013 with Z Clauses. Tenderers should note that Phase 2 is a Term Service Contract with no guarantee of spend under Part 2 Services. Phase 2 contract shall commence when practical completion has been achieved under the Phase 1 contract (anticipated to be 2 months from the contracts start date) and run for a period of 5 years.",
"status": "complete",
"hasOptions": false
}
],
"coveredBy": [
"GPA"
],
"classification": {
"id": "45317000",
"scheme": "CPV"
},
"reviewDetails": "An economic operator that suffers or risks suffering, loss or damage attributable to breach of duty under the Public Contracts (Scotland) Regulations 2015 (SSI 2015/446, as amended) may bring proceedings in the Sheriff Court or the Court of Session in accordance with Regulation 88 of the 2015 Regulations."
},
"awards": [
{
"id": "RC-CPU-20-092",
"suppliers": [
{
"id": "org-333",
"name": "SWARCO UK LTD"
}
],
"relatedLots": [
"1"
]
}
],
"contracts": [
{
"id": "RC-CPU-20-092",
"awardID": "RC-CPU-20-092",
"status": "active",
"value": {
"amount": 65870.27,
"currency": "GBP"
},
"dateSigned": "2021-03-31T00:00:00Z"
}
],
"language": "EN",
"description": "(SC Ref:650700)",
"bids": {
"statistics": [
{
"id": "1069",
"measure": "bids",
"value": 2,
"relatedLot": "1"
},
{
"id": "1070",
"measure": "smeBids",
"value": 2,
"relatedLot": "1"
},
{
"id": "1071",
"measure": "foreignBidsFromEU",
"value": 0,
"relatedLot": "1"
},
{
"id": "1072",
"measure": "foreignBidsFromNonEU",
"value": 2,
"relatedLot": "1"
},
{
"id": "1073",
"measure": "electronicBids",
"value": 2,
"relatedLot": "1"
}
]
},
"links": [
{
"rel": "canonical",
"href": "https://api.publiccontractsscotland.gov.uk/v1/Notice?id=ocds-r6ebe6-0000650700"
}
],
"noticetype": "PCS Notice - Website Contract Award Notice"
}